TINKER AFB MAC BOA WWYK190099 INSULATE AND INSTALL VAPOR BARRIER ON EXISTING HEATING AND CHILLED WATER PIPE B3708

Form / Attachment / Pricing Sheet

This document is a sign-in sheet for an initial site visit related to Project No. WWYK190099, titled "Repair Heating - Chill Piping B3708". It records attendees and their organizations.

• Date of Site Visit: 2026-04-15
• Time of Site Visit: 0900
• Project Number: WWYK190099
• Project Title: Repair Heating - Chill Piping B3708
• Type of Site Visit: Initial Site Visit
• RFI Due Date: 2026-04-21
• Proposal Due Date: 2026-05-18
• List of attendees, their organizations, and whether they are Prime Contractors.

This document confirms attendance at the initial site visit and provides crucial deadlines for RFIs (2026-04-21) and proposal submissions (2026-05-18). It also lists other companies that attended, which may be useful for networking or understanding the competitive landscape.

Solicitation / RFP / RFQ

This solicitation is for the "Insulate & Install Vapor Barrier on Existing Heating & Chilled Water Pipe" project at Building B3708, F3Y0AB. The work involves removing existing vapor retardant material and insulation on the chilled water piping and replacing it with new.

• Removal of existing vapor retardant material and insulation on chilled water piping.

• Installation of new vapor retardant material and insulation on chilled water piping.

• The contract type is anticipated to be Firm-Fixed-Price (FFP).

• Performance period is 10 calendar days to complete within 179 calendar days after award/notice to proceed.

• Offers are due by 02:00 PM local time on May 18, 2026.

• Offers must be valid for at least 120 calendar days.

• The solicitation includes FAR clauses related to inspection, delivery, payment, and contract administration.

• This solicitation is a 100% Small Business Set-Aside.

• NAICS Code: 236220 (Commercial and Institutional Building Construction).

• Size Standard: $45,000,000.00 Annual Receipts.

• The document includes numerous FAR and DFARS clauses covering various aspects of the contract, including payment, administration, and compliance.

• Specific clauses address electronic submission of payment requests (WAWF), Buy American requirements, and limitations on subcontracting.

Other / Unclassified

This document is a "List of Drawings" for the "B2 AVIONICS FACILITY" project at Tinker Airforce Base, Oklahoma City, Oklahoma. It provides a comprehensive index of all architectural, civil, electrical, mechanical, and structural drawings associated with the project. The list is organized by discipline and includes drawing numbers and titles.

This document is relevant to bidders as it serves as a table of contents for the entire set of construction drawings. Potential bidders can use this list to quickly identify and locate specific drawings related to their scope of work, such as site layout, structural details, electrical plans, mechanical systems, and architectural features. Understanding the full scope of the project requires reviewing these referenced drawings.

Forms / Attachments / Pricing Sheets

This document contains the "General Notes, Vicinity Plan & Project Data" for the "Modernize HVAC B/3708" project at Tinker AFB, OK. It serves as an introductory and foundational document for the project.

• General Notes: Includes information on brand name references, contractor responsibilities for understanding all documents, construction fencing and barricades, and repair of damages caused by construction.
• Vicinity Map: Illustrates the project location within Tinker AFB.
• Project Drawing Index: Lists all the drawings included in the project set, organized by sheet number and description.
• Signatures: Section for official sign-offs from various engineering and safety personnel.
• Project Information: Includes project number (WWYK 020257), project title, issue date, design information, and revision history.

This document provides essential context for bidders, including the project's location, scope overview through the drawing index, and critical general notes that outline responsibilities and standards. It is crucial for understanding the overall project documentation and requirements.

Statement of Work (SOW) / Performance Work Statement (PWS)

This document outlines the repair of the air ventilation system in Room 125 of Building 3708 at Tinker Air Force Base.

• Demolition of existing exhaust fans, associated controls, and louvers.

• Removal of existing dampers, actuators, and linkages.

• Installation of new filter banks (Farr 30/30).

• Installation of new pneumatic actuators and linkages for dampers.

• Installation of new electric temperature controllers to activate dampers and exhaust fans.

• Reconnection of existing feeders to new exhaust fans.

• Disconnection of existing feeders to old exhaust fans, with existing circuits and raceways to remain for future use.

• Replacement of roof flashing if required.

• New exhaust fans (Cook, Model 330C5B) are specified for continuous duty operation.

• Installation must comply with NFPA 70 (NEC 2005), National Electrical Safety Code, Air Force Regulations, and Tinker AFB policies.

• Coordination with the electrical contractor for fan installation and continuous duty operation is required.

• Backdraft dampers and motor disconnects are required for the new exhaust fans.

• A minimum 12" high insulated roof curb is required for the prefabricated exhaust fans.

• The project is located at Building 3708, Room 125, Tinker Air Force Base, Oklahoma.

• The contractor must submit a schedule of activities, including electrical outages, for approval by the user and USACE. All scheduled electrical outages require 21 days' written notice to the Contracting Officer.

• The contractor shall complete as much new work as possible without disrupting existing electrical service.

• The contractor is responsible for obtaining existing utilities plans and notifying the Contracting Officer's Representative of any conflicts.

• Environmental requirements as stated in Design Standards Section 00720 and SOW Section 01110 must be adhered to.

• Brand names are for minimum quality standards; equal or exceeding products may be submitted for approval.

• The contractor is responsible for construction fencing, barricades, and repair of any damage caused by construction operations.

• A staging area and construction area physical protection plan, as well as a dust control plan, must be submitted for approval prior to work commencement.

Statement of Work (SOW) / Performance Work Statement (PWS)

This document outlines the scope of work for repairing the humidification system in Building 3708 at Tinker Air Force Base.

• Repair and replacement of components within the humidification system.

• Installation of new steam distribution manifolds (SDM-1 through SDM-6).

• Integration of new components with existing Air Handling Units (AHUs) and utilities.

• Specific tasks include piping modifications, equipment connections, and control system integration.

• All new work must comply with current applicable codes and regulations.

• Materials and equipment are guaranteed for one (1) year from final acceptance.

• The contractor is responsible for verifying all dimensions and conditions prior to construction.

• Any damage caused by construction traffic must be repaired by the contractor.

• The project is located at Building 3708, Tinker Air Force Base, Oklahoma.

• Specific period of performance is not detailed in this document, but it is issued for construction.

• Contractor must coordinate all shutdowns with the Contracting Officer Representative (COR).

• Contractor must coordinate phasing with the user's production schedule.

• Contractor must maintain manufacturer's recommended clearances for all equipment.

• The project requires a fully operational humidification system as per drawings and specifications.

Other / Unclassified

This document is a General Decision Number (GDN) for wage determination in Oklahoma County, Oklahoma. It specifies prevailing wage rates and fringes for various construction-related trades, including Bricklayer, Millwright, Carpenter, Electrician, Elevator Mechanic, Power Equipment Operator, Ironworker, Plumber, HVAC Mechanic, Pipefitter, Roofer, Sprinkler Fitter, Sheet Metal Worker, and others. It also includes details on paid holidays and notes regarding Executive Orders 13706 (Establishing Paid Sick Leave for Federal Contractors) and 13658 (Establishing a Minimum Wage for Federal Contractors).

This document is crucial for bidders on construction-related opportunities in Oklahoma County, Oklahoma. It establishes the minimum wage rates and fringe benefits that must be paid to laborers and mechanics employed on covered federal contracts. Bidders must review these rates to accurately estimate labor costs and ensure compliance with federal labor standards, which can significantly impact bid competitiveness and project feasibility.

Statement of Work (SOW) / Performance Work Statement (PWS)

This Statement of Work (SOW) details the requirements for insulating and installing vapor barriers on existing heating and chilled water pipes at Building B3708, Tinker Air Force Base, Oklahoma.

• Furnish all materials, labor, plant, tools, transportation, equipment, testing services, quality control, and incidentals for the replacement of chilled water piping insulation.

• Perform a site investigation to verify existing conditions and obtain as-built drawings if necessary.

• Identify and perform necessary logistical, architectural, and structural work.

• Provide assemblies, frameworks, fixtures, or apparatus not explicitly identified in the drawings or specifications.

• Demolish existing vapor barrier/retardant material and pipe insulation on existing chilled water piping.

• Install new cellular glass pipe insulation with all-service jacket, self-sealing lap, and vapor barrier jacket.

• The work is to be performed at Building B3708, Tinker Air Force Base, Oklahoma.

• Construction is to take place during normal duty hours (0700 – 1600 Monday-Friday), with utility outages as an exception.

• Contractor Personnel: Must possess current/valid licenses and certifications. Personnel must be easily recognizable as contractor employees. Key personnel include Project Manager (PM), Quality Control Manager (QCM), Site Safety and Health Officer (SSHO), and Project Superintendent, each with specific experience requirements and designated alternates. Resumes for key personnel are due within five (5) calendar days after NTP.

• Badges: AFMC Form 387 (contractor badges) are required for access to Tinker AFB. Personnel must be badged prior to commencing work.

• Quality Control: Contractor is responsible for providing, inspecting, and documenting quality. A QC Plan must be established, including an inspection system, deficiency prevention methods, and inspection files.

• Health and Safety: Adherence to the Commander's Statement of Safety Intent, OSHA Voluntary Protection Program (VPP), Emergency Evacuation Procedures, Mishap Reporting, and Bioenvironmental Regulations is required. Compliance with EM 385-1-1 is mandatory.

• Controlled/Restricted Area: Work is located in a controlled area requiring AF Form 1199C (Secure Area Badge). Escorts are required for personnel access, with specific submission timelines for Entry Access Lists (EAL) and Vehicle Entry Access Lists (VEAL).

• FOD Awareness: All personnel must complete Foreign Object Debris (FOD) awareness and prevention training.

• Construction Schedule: A baseline construction schedule must be submitted within ten (10) calendar days after NTP. Updates are required monthly.

• Submittals: Various submittals are required, including preconstruction submittals, health and safety plans, material submittals, and construction submittals, with specific government review times.

• Documentation: All documents must be submitted electronically in Adobe Acrobat (.pdf) format. Drawings must be in AutoCAD (.dwg) format for final design and as-built record drawings.

• Order of Precedence: Defines the hierarchy for resolving conflicts between solicitation provisions, accepted proposals, and contractor-generated documents.

• Record Drawings: Working as-built drawings must be maintained on-site and submitted for approval. Final record drawings incorporating redlines are required within ten (10) days after pre-final inspection.

• Government Furnished Information: Drawings, specifications, and reference documents are provided on an attached CD.

• Attachments: Includes Appointment of Security Representative Letter, Controlled Area Training and Procedures, and Recovered Materials Determination Form.

Form / Attachment / Pricing Sheet

This document contains architectural and engineering drawings related to the "WWYK190099 REPAIR HEATING & CHILLED WATER PIPING AVIONICS FACILITY B3708" project at Tinker Air Force Base, Oklahoma. It provides detailed plans for demolition and new work, as well as mechanical details.

• Sheet G-101: General Notes and Vicinity Map, showing the project location and general construction guidelines.
• Sheet MD-101: Mechanical Demolition Plan, detailing areas and components to be removed, including existing insulation on chilled water piping.
• Sheet M-101: Mechanical New Work Plan, outlining the installation of new insulation systems for chilled water piping and reinstallation of ceiling grids and fixtures.
• Sheet M-501: Mechanical Details, illustrating specific insulation practices for pipes, valves, fittings, and wall penetrations, and providing general notes.

These drawings are critical for bidders to understand the scope of work, including demolition requirements, new installation specifications for heating and chilled water piping insulation, and the specific areas within Avionics Facility B3708 affected by the project. They provide the technical basis for estimating costs and planning execution.

Form / Attachment / Pricing Sheet

This document is a Submittal Register for the "Insulate and Install Vapor Barrier on Existing Heating & Chilled Water Pipe" project (Job Name: WWYK190099). It serves as a tracking log for all required submittals from the contractor to the government or architect/engineer (A/E).

• Line Item #: Unique identifier for each submittal.
• Submittal #: Sequential number for the submittal.
• Specification Section #: The relevant section of the project specifications.
• Submittal Description: A brief description of the item being submitted (e.g., Health and Safety Plan, Materials List, Pipe Insulation Systems).
• Item Submitted: Classification of the submittal (e.g., Product Data, Shop Drawings, Certificates).
• Paragraph #: Specific paragraph within the specification.
• Classification: Indicates if the submittal is for Government or A/E review.
• Contractor Action Dates: Columns for tracking when the contractor submits, when materials are needed, and when action is needed by the contractor.
• Approving Authority Dates: Columns for tracking review, approval, and receipt dates by the Government/A/E and other reviewers.
• Remarks: Additional notes or instructions related to the submittal.

This register is crucial for bidders to understand the full scope of documentation and approvals required throughout the project lifecycle. It outlines specific deliverables such as preconstruction submittals (e.g., safety plans, work schedules), product data, shop drawings, and closeout submittals. Bidders should review this list to ensure they can meet all documentation requirements and to understand the timeline for approvals, which can impact project progress.