Z1DA--Renovate Dialysis PN: 636A8-24-001 Iowa City, IA

Amendment / Modification

• The Bid Opening due date has been extended by 17 calendar days.

• The new Bid Opening time is 1:30 PM (CT) on Friday, 13 February 2026.

• The previous Bid Opening was scheduled for 2:30 PM (CT) on Wednesday, 28 January 2026.

• This extension is due to delays in responses to Pre-Bid Site Visit questions.

• Bid Opening due date and time.

• The deadline for submitting offers has been extended to 1:30 PM (CT) on Friday, 13 February 2026.

Amendment / Modification

This amendment (0001) to solicitation 36C26326B0005 revises the "Technical Questions and Inquiries" section and extends the deadline for submitting pre-bid site visit questions.

Specifically:

• The deadline for submitting technical questions and inquiries related to the pre-bid site visit has been extended by seven (7) calendar days, moving from Friday, January 9, 2026, at 2:00 PM (CT) to the close of business on Friday, January 16, 2026.

• The verbiage regarding late questions has been revised. Previously, no late questions would be accepted or answered. Now, late questions will only be accepted or answered at the Contracting Officer's discretion.

• Technical Questions and Inquiries section of the IFB Contracting Officer's Special Information and Instructions.

• The deadline for submitting questions has been extended to January 16, 2026.

• The bid opening date remains unchanged at Wednesday, January 28, 2026, at 2:30 PM (CT).

Solicitation / RFP / RFQ

This document provides special instructions and information for bidders responding to a solicitation. It details requirements for contract award, contractor signatures, site visits, technical inquiries, bid submission, and bid opening procedures.

• Contract Award: Award will be made to the responsible bidder whose bid is most advantageous to the government, considering price and ensuring it is fair and reasonable.

• Contractor Signature: Specific signature requirements are outlined for individuals, partnerships, corporations, joint ventures, and agents. Digital signatures are acceptable if using PIV/CAC.

• Site Visit: A site visit is scheduled for Monday, December 1, 2025, at 1:00 PM (CT) at 601 US-6, Iowa City, IA 52246, Building 2, Room 204A.

• Technical Questions: All technical questions and inquiries must be submitted in writing via email to calvin.courtney@va.gov by COB on Friday, December 16, 2025. The subject line must be 'PN: 636A8-24-001; Construction – Renovate Dialysis'. Telephone inquiries are not accepted.

• Bid Submission: Bids must be submitted electronically via email to calvin.courtney@va.gov by 2:30 PM (Central Time) on Tuesday, December 30, 2025. Email size limit is 5MB. Required documents include SF 1442, Acknowledgement of Amendments, Price Schedule, Bid Guarantee (SF 24), Tax Representation (FAR 52.229-11), Representations & Certifications (FAR 52.204-7), Post Award Small Business Program Representations (FAR 52.219-28), Limitations on Subcontracting (VAAR 852.219-75), Information Regarding Responsibility Matters (FAR 52.209-7), and Violation of Arms Controls Treaties (FAR 52.209-13).

• Bid Guarantee: A bid guarantee (SF 24) of at least 20% of the bid price (not to exceed $3,000,000.00) is required.

• Bonds: Performance and payment bonds (SF25, SF25A) for 100% of the award amount are required within ten days after award.

• Responsibility Determination: The apparent low bidder will undergo a responsibility determination based on financial resources, performance record, integrity, and technical capabilities.

• VETS 4212 Reporting: Award cannot be made unless the awardee has filed their VETS-4212 report.

• SAM Registration: Offerors must be registered in the System for Award Management (SAM) at the time of offer submission.

• Background Investigations: Contractor employees are subject to background investigations; costs are borne by the contractor.

• HHS/OIG Exclusions: Contractors must check the OIG Exclusions Database for personnel and certify that no listed individuals are used.

• Bid Submission Deadline: Tuesday, December 30, 2025, at 2:30 PM (Central Time).

• Bid Opening: A teleconference bid opening will be held. Details: 1 872-701-0185, Phone Conference ID: 681 084 301#.

• Evaluation: Award is based on the most advantageous offer considering price, and requires a determination of responsibility.

• Specific requirements for joint ventures (SDVOSB/Mentor Protégé) are mentioned.

• Offerors must comply with FAR Part 9 for responsibility.

• Amendments will be posted on SAM.gov; bidders are responsible for obtaining and acknowledging them.

• The Contracting Officer’s Representative (COR) replaces references to "VA Engineer," "Resident Engineer," or "Project Manager."

Technical Specifications / Construction Documents

This document comprises Volume 1 of the Technical Specifications for the "Renovate Dialysis" project, VA Project Number: 636A8-24-001, located at 601 HWY 6 West, Iowa City, IA 52246. Issued for Construction Documents on April 24, 2025, it details specifications for Divisions 00 through 14.

Division 00 - Special Sections:

• 00 01 15 - List of Drawing Sheets: References a list of drawing sheets that form part of the contract.

Division 01 - General Requirements:

• 01 00 00 - General Requirements: Outlines safety requirements, general intentions, bid item statements, specifications and drawings availability, construction security requirements, operations and storage areas, and restoration procedures.
• 01 33 23 - Shop Drawings, Product Data, and Samples: Defines requirements for submittals, including shop drawings, product data, and samples.
• 01 35 26 - Safety Requirements: Details applicable publications, definitions, accident prevention plans, activity hazard analyses, preconstruction safety conferences, safety meetings, site safety and health officer roles, training, inspections, mishap reporting, and personal protective equipment (PPE).
• 01 42 19 - Reference Standards: Lists and provides availability information for various standards and specifications cited in the project manual.
• 01 45 00 - Quality Control: Outlines requirements for contractor quality control (CQC) for design-bid-build construction projects, including CQC plans, submittals, and testing procedures.
• 01 45 29 - Testing Laboratory Services: Specifies requirements for materials testing and inspection services to be provided by a testing laboratory retained by the General Contractor.
• 01 57 19 - Temporary Environmental Controls: Details requirements for the control of environmental pollution and damage, including management of air, water, and land resources, noise reduction, and waste management.
• 01 58 16 - Temporary Interior Signage: Specifies requirements for temporary interior signs.
• 01 74 19 - Construction Waste Management: Outlines requirements for the management of non-hazardous building construction and demolition waste, emphasizing diversion from landfills.
• 01 81 13 - Sustainable Construction Requirements: Describes general requirements and procedures to comply with federal mandates and VA policies for sustainable construction.
• 01 91 00 - General Commissioning Requirements: Forms the basis of the construction phase commissioning process and procedures, including roles and responsibilities of the commissioning team.

Divisions 02-12 - Specific Trades and Systems:

• Division 02 - Existing Conditions: Includes sections on Demolition (02 41 00), Asbestos Abatement (02 82 13.13, 02 82 11), and others.

• Division 05 - Metals: Includes Metal Fabrications (05 50 00).

• Division 06 - Wood, Plastics and Composites: Includes Rough Carpentry (06 10 00).

• Division 07 - Thermal and Moisture Protection: Includes Preparation for Re-Roofing (07 01 50.19), Firestopping (07 84 00), and Thermal Insulation (07 21 13).

• Division 08 - Openings: Includes Hollow Metal Doors and Frames (08 11 13), Glazing (08 80 00), ICU Sliding Glass Doors (08 32 13), Door Hardware (08 71 00), and Interior Wood Doors (08 14 00).

• Division 09 - Finishes: Includes Subsurface Preparation for Floor Finishes (09 05 16), Ceramic/Porcelain Tiling (09 30 13), Non-Structural Metal Framing (09 22 16), Acoustical Ceilings (09 51 00), Resilient Sheet Flooring (09 65 16), Resilient Base and Accessories (09 65 13), and Painting (09 91 00).

• Division 10 - Specialties: Includes Signage (10 14 00), Cubicle Curtain Tracks (10 21 23), Wall and Door Protection (10 26 00), Toilet, Bath, and Laundry Accessories (10 28 00), and Fire Extinguisher Cabinets (10 44 13).

• Division 11 - Equipment: Includes General Motor Requirements for Equipment (11 05 12) and Ceiling Mounted Patient Lift System (11 73 00).

• Division 12 - Furnishings: Includes Manufactured Wood Casework (12 32 00) and Window Shades (12 24 00).

• Division 21 - Fire Suppression: Includes Wet-Pipe Sprinkler Systems (21 13 13).

• Division 22 - Plumbing: Includes various plumbing system requirements.

• Division 23 - Heating, Ventilating, and Air Conditioning (HVAC): Includes various HVAC system requirements.

• Division 26 - Electrical: Includes various electrical system requirements.

• Division 27 - Communications: Includes various communication system requirements.

• Division 28 - Electronic Safety and Security: Includes various electronic safety and security system requirements.

• Division 31 - Earthwork: Includes demolition and excavation requirements.

• The document includes a "Certifications Page" listing Architect and Professional Engineer certifications.

• Appendices include information on pre-renovation asbestos surveys, reverse osmosis, and VA-provided risk assessment information.

• The document is "Issue for Construction Documents" and dated April 24, 2025.

• It references numerous ASTM, ANSI, NFPA, and other industry standards.

Form / Attachment / Pricing Sheet

This document is VAAR 852.219-75, VA Notice of Limitations on Subcontracting—Certificate of Compliance for Services and Construction (JAN 2023) (DEVIATION). It requires offerors to certify their compliance with subcontracting limitations.

• Services: Contractors must not pay more than 50% of the contract amount to firms that are not certified Service-Disabled Veteran-Owned Small Businesses (SDVOSBs) or Veteran-Owned Small Businesses (VOSBs).
• General Construction: Contractors must not pay more than 85% of the contract amount to firms that are not certified SDVOSBs or VOSBs.
• Special Trade Construction: Contractors must not pay more than 75% of the contract amount to firms that are not certified SDVOSBs or VOSBs.
• Certification Acknowledgment: Offerors acknowledge that false certifications are subject to penalties under Title 18, United States Code, Section 1001.
• Consequences of Non-Compliance: Failure to comply may result in penalties, including referral to the VA Suspension and Debarment Committee, fines, and prosecution.
• Cooperation: Offerors agree to provide documents to VA to demonstrate compliance.
• Required Action: The certification must be completed, signed, and returned with the offeror's bid, quotation, or proposal. Offers without this certification will be deemed ineligible for award.

This is a mandatory certification for all offerors. Failure to complete and submit this form correctly will result in the offer being deemed ineligible for award. Bidders must understand and agree to the specified subcontracting limitations based on the contract type (services, general construction, or special trade construction) to ensure compliance if awarded the contract.

Form / Attachment / Pricing Sheet

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the SAT, for the Department of Veterans Affairs. It justifies the procurement of specific brand-name speakers (EST) for the "Renovate Dialysis" construction project at the VAMC Iowa City.

• Acquisition Details: Identifies the Contracting Activity, Project Number, and Acquisition Plan Action ID.
• Description of Supplies/Services: Specifies the need for EST brand-name speakers for fire alarm notification and hospital public address overhead paging.
• Technical Requirements for Speakers:
  • Operate on 25 VRMS or 70.7 VRMS with field-selectable output taps (0.5 to 2.0W).
  • Minimum sound output of 80 dBA at 10 feet (at 1/2 watt tap).
  • Frequency response: 400 Hz to 4,000 Hz.
  • Size: 4-inch or 8-inch cone type, ceiling or wall mounted.
• Unique Characteristics: Justifies brand-name procurement due to the need for compatibility with the existing fire alarm control panel (FACP) or voice evacuation system, which requires flexibility in voltage and seamless integration.
• Market Research: States that EST equipment is currently used throughout the facility, and new components must be compatible with the existing system. No competing vendors' products are fully compatible.
• Contracting Officer's Certification: Certifies the accuracy and completeness of the justification.

This document indicates that the upcoming procurement for speakers in the "Renovate Dialysis" project will likely be brand-name specific to EST. Bidders should note that compatibility with the existing VA facility infrastructure and systems is a critical requirement, potentially limiting competition to vendors offering EST products or fully compatible alternatives.

Form / Attachment / Pricing Sheet

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the Simplified Acquisition Threshold (SAT), not exceeding $250K. It justifies the procurement of a specific brand-name product, the "Infinity" brand line manufactured by ASI Sign Systems, Inc., for the "Renovate Dialysis" project at the Iowa City Veterans Affairs Health Care System (ICVAHCS).

• Requirement: Signage for 19 rooms as part of the "Renovate Dialysis" project.
• Brand Name: Infinity brand line by ASI Sign Systems, Inc.
• Justification: The "Infinity" signage is the only signage currently installed at ICVAHCS and is required to accommodate standardization throughout the medical facility. This ensures uniform sign type, typography, and ease of maintenance, aligning with the VA Signage Design manual and an ongoing program to update all room signage to the latest VA standard.
• Market Research: Conducted prior to selecting ASI Sign Systems as the facility's standard.
• Contracting Officer Certification: The purchase is approved in accordance with FAR 13.106-1(b).

This document indicates that the upcoming solicitation for the "Renovate Dialysis" project will likely specify the "Infinity" brand line of signage from ASI Sign Systems, Inc. Bidders should be aware of this brand name requirement, as it may limit competition and impact their ability to propose alternative solutions. The justification highlights the need for standardization and compatibility with existing facility signage.

Justification for Brand Name Award

This document justifies a brand name award for the procurement of Handicare C-Series Ceiling Mounted Patient Lift Systems for the Veterans Health Administration (VHA) at the Iowa City VAMC. The procurement is for construction materials related to the "Renovate Dialysis" project and is over the micro-purchase threshold but not exceeding the SAT ($250K).

The specific requirement is for the Handicare C-Series Ceiling Mounted Patient Lift System, which must include features such as:

• Lifting capacity: 625 lbs. (284 kg)

• Electronic soft-start and soft-stop motor control

• Emergency lowering and stopping devices

• Current limiter for overload protection

• Safety device for low batteries

• Horizontal axis motor

• Emergency brake

• Specific strap length

• VO plastic-fire retardant, UL 94 cab

• The approximate value of the Handicare Patient Lift System is redacted.

• The justification covers only the brand-name portion of the acquisition.

This document is a justification for a brand name award, not a solicitation. It details why other than full and open competition is being used.

This justification is for brand name award, limiting competition.

• The justification cites FAR 13.106-1 and FAR 11.105 (Items Peculiar to One Manufacturer).
• Reasons for brand name justification include:
  • Standardization of slings, lift motors, staff training, and maintenance.
  • Avoiding safety risks from mixing incompatible equipment.
  • Reducing logistical burdens for laundry and sterile processing.
  • Preventing substantial and unnecessary duplication of costs for new equipment, installation, and training.
  • Ensuring compatibility with existing Handicare systems at the facility.
• Market research indicated that other brands are not compatible with the existing Handicare system.
• The Contracting Officer has approved the justification.

Other / Unclassified

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the Simplified Acquisition Threshold (SAT), not exceeding $250K. It justifies the procurement of the Rauland Responder 5 Nurse Call System for the Renovate Dialysis project at the Iowa City VA Health Care System (ICVAHCS) as a firm-fixed price contract. The justification is for other than full and open competition, citing that the specific brand name is required for standardization and compatibility with the existing system.

• Procurement Type: This document indicates a sole-source or limited competition procurement for a specific brand name nurse call system.
• Product: The required item is the Rauland Responder 5 Nurse Call System, including all associated components, programming, and updates.
• Reason for Sole Source: The existing ICVAHCS facility already uses the Rauland Responder 5 system. Replacing it with a different brand would necessitate purchasing new computers, retraining staff, and would be costly, potentially leading to system downtime and impacting patient safety and staff efficiency. Standardization is critical for seamless integration and operational continuity.
• Market Research: While many companies can install and service nurse call systems, only a limited number are authorized and possess the technical expertise for the specific Rauland Responder 5 system. Approval as brand name only is deemed critical for project efficiency.
• Contracting Activity: Veterans Health Administration (VHA), NCO 23 Contracting Office, Department of Veterans Affairs, VISN 23, VAMC Iowa City.
• Project: Renovate Dialysis project.
• Effective Date: November 15, 2024.

Other / Unclassified

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the SAT, in accordance with FAR 13.106-1. It justifies the use of Johnson Controls - Tyco/Simplex brand name for fire alarm hardware for the "Renovate Dialysis" project at the Iowa City VA Medical Center.

This justification explains that the existing fire alarm system at the facility uses Tyco/Simplex components. To ensure seamless integration, compatibility, and maintainability, new components must also be Tyco/Simplex. The document highlights that other manufacturers' systems may not integrate with the current fire alarm panels and monitoring software, potentially compromising the life safety system's integrity and violating safety codes. It also notes that Tyco Simplex technicians are familiar with the facility, ensuring proper support and emergency service. This document is relevant to bidders as it explains the rationale for a brand-name-only acquisition for specific fire alarm components, impacting the types of products and services that can be proposed.

Form / Attachment / Pricing Sheet

This document is a Brand Name Justification for awarding a contract for electrical distribution hardware for the Renovate Dialysis project at the Iowa City VA Health Care System (ICVAHCS). It supports a firm-fixed price contract and is for other than full and open competition.

• Supplies/Services: Square D electrical distribution hardware, including electrical panel boards and overcurrent devices.
• Reason for Brand Name: The ICVAHCS has an existing installed system primarily using Square D brand equipment. New components must be compatible with the existing facility electrical distribution hardware to ensure system integrity, hardware reliability, parts availability, and maintenance familiarity. Using non-standard equipment could lead to system shutdown, incompatibility, compromise safety and reliability, void warranties, or complicate technical support. A total redesign and replacement would be significantly more costly.
• Market Research: Previous contract bidding identified Square D as the facility standard. Market research confirmed that Square D is currently used throughout the facility, and new components must tie into the existing system. Currently, no competing vendors' products are fully compatible.
• Contracting Activity: Veterans Health Administration (VHA), NCO 23 Contracting Office, Department of Veterans Affairs, VISN 23, VAMC Iowa City.
• Project: 636A8-24-001 Const – Renovate Dialysis.
• Acquisition ID: 36C263-26-AP-0384
• Estimated Amount: Over Micro-Purchase Threshold but Not Exceeding the SAT ($250K).

This justification indicates that the upcoming procurement for the Renovate Dialysis project will likely specify Square D electrical distribution hardware due to existing facility standards and compatibility requirements. While the overall procurement will be competed as a Service-Disabled Veteran-Owned Small-Business (SDVOSB) Set-Aside, bidders should be aware of the brand-specific nature of this component.

Other / Unclassified

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the SAT, for door hardware cylinders. It justifies the procurement of CORMAX Best (Stanley Security) brand cylinders for the "Renovate Dialysis" project at the Iowa City VA Health Care System (ICVAHCS).

This justification is critical for bidders as it specifies a brand-name requirement for door cylinders. The government's rationale for this brand-name-only approach is to ensure standardization with the existing key system, reduce maintenance and repair costs, and maintain facility security. Bidders need to understand that the requirement is for CORMAX Best (Stanley Security) cylinders due to their unique characteristics and compatibility with the facility's current master key system. The document indicates that while the specific cylinders are brand-name, there will be competition for the overall procurement, and offerors will be responsible for obtaining pricing from suppliers. Future procurements for full door cylinder replacement may be competitively acquired.

Other / Unclassified

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the SAT for the Department of Veterans Affairs. It justifies the procurement of specific construction materials, namely the Genasys "code green" system, for the Iowa City VA Health Care System (ICVAHCS). The justification is based on the need for standardization and the proprietary nature of the Genasys system, which is already installed and established as the standard within the facility. The system is used for targeted, multi-channel communication, data-driven decision making, and inter-agency collaboration, and must align with VA, NIST, and FIPS guidelines.

This document is relevant to potential bidders as it explains the rationale behind a brand-name-only requirement for the Genasys "code green" system. It indicates that the procurement is for integrating new hardware and software from Genasys with the existing system. While the justification is for a brand-name item, the overall procurement is stated to be competed as a Service-Disabled Veteran-Owned Small-Business (SDVOSB) Set-Aside. Market research was conducted prior to selecting this manufacturer. The approximate value of the Genasys portion of the acquisition is redacted.

Form / Attachment / Pricing Sheet

This document is a Brand Name Justification for Simplified Acquisition Procedures (SAP) under the SAT, justifying the procurement of the Lenel Access Control System (ACS) as a brand-name item. It explains why only this specific system can meet the requirements for the "Renovate Dialysis" project at the VAMC Iowa City.

• Contracting Activity: VHA, NCO 23 Contracting Office, VISN 23, VAMC Iowa City.
• Project: 636A8-24-001 Const – Renovate Dialysis.
• Supplies/Services: Lenel Access Control System (ACS), specifically PC-based physical access control system (PACS) integrating access control, alarm monitoring, and video surveillance.
• Key Features: Integrated security, scalability, data integration, situational awareness, PC-based management, advanced technologies (biometrics, smart cards), open architecture, and mobile/web accessibility.
• Justification for Brand Name: The need for compatibility with an existing, proprietary Lenel system to prevent costly replacements and security vulnerabilities. Seamless integration with existing infrastructure, personnel training on Lenel software, and the requirement to integrate with existing remote monitoring centers are critical.
• Market Research: Lenel was selected in a previous contract bidding process as the standard for Iowa City VAMC. Non-Lenel components cannot be added due to the proprietary nature of the system, and source changes would be cost-prohibitive. Standardization is essential for overall facility security.
• Estimated Value: The approximate value of the Lenel Access Control System (ACS) is [REDACTED] per unit.

This document indicates that the upcoming acquisition for the "Renovate Dialysis" project will specifically require the Lenel Access Control System (ACS). Bidders should note that this is a brand-name justification, meaning proposals will likely need to be for the specified Lenel system or components compatible with the existing Lenel infrastructure. The justification highlights the importance of integration with existing systems and personnel familiarity with Lenel, which may influence the scope of work and required expertise for potential offerors.

Other / Unclassified

This document is a Justification for Single Source Awards (JSSA) for a Simplified Acquisition Procedure (SAP) under the Simplified Acquisition Threshold (SAT) for the Department of Veterans Affairs (VA). It justifies the use of Johnson Controls (JCI) as a single source for control systems for the Renovate Dialysis construction project at the Iowa City VA Health Care System (ICVAHCS).

This document is relevant to potential bidders as it explains why a specific vendor (JCI) is being selected for a portion of the Renovate Dialysis project. It highlights that JCI's Metasys systems are proprietary and require unique interfaces, making other manufacturers' equipment incompatible. The need for standardization, interoperability with the existing system, and the high cost of conversion are cited as reasons for this single-source justification. Bidders should note that this justification pertains specifically to the JCI control systems and not the entire construction project.

Form / Attachment / Pricing Sheet

This document is an Asbestos Inspection Report for the "Renovate Dialysis" project at the Iowa City VA Health Care System, Building 1, 5th Floor. It details the findings of an asbestos survey conducted prior to renovation to identify and quantify Asbestos-Containing Materials (ACM).

• Scope: Survey conducted on 5th floor south (5S) and a limited survey on 5th floor west (5W).
• Methodology: 84 bulk samples collected and analyzed by polarized light microscopy (PLM).
• Findings:
  • Asbestos-Containing Materials Identified:
    • Gray adhesive on plaster (Sample 6A)
    • 12" x 12" floor tile, white with gray (Sample 102)
  • Assumed Materials (not sampled but treated as ACM):
    • Fire doors (7 doors)
    • Electric panels (5 panels)
  • Non-Asbestos Materials: Numerous materials were sampled and found to contain no asbestos.
• Quantities: Estimated quantities for identified ACM include 10 sf of gray adhesive on plaster and 100 sf of 12" x 12" floor tile.
• Recommendations: Remove identified ACM in accordance with specifications. If untested materials are discovered, stop work immediately and assume they contain asbestos or test them. Provide this report to contractors.

This report is critical for bidders as it identifies specific materials containing asbestos that may be present in the renovation area. Bidders must be aware of these materials to ensure proper handling, abatement, and safety protocols are followed during the "Renovate Dialysis" project, which will impact construction planning and costs.

Technical Specifications - Volume 2: Divisions 21-48

This document contains technical specifications for Volume 2, Divisions 21-48, for the "Renovate Dialysis" project at the VA Project Number: 636A8-24-001, located at 601 HWY 6 West, Iowa City, IA 52246. The issue is for Construction Documents, dated April 24, 2025. The document was prepared by Anderson Engineering of MN, LLC, in association with IMEG Corp.

This volume appears to cover a broad range of technical specifications for the "Renovate Dialysis" project, likely including:

• Division 21: Fire Suppression (e.g., Wet-Pipe Sprinkler Systems - Section 21 13 13)
• Division 22: Plumbing (e.g., Common Work Results for Plumbing, Meters and Gauges, General-Duty Valves, Plumbing Insulation, Facility Water Distribution, Facility Sanitary and Vent Piping, HVAC Water Treatment, HVAC Ducts and Casings, HVAC Fans, Motor Controllers, Enclosed Switches and Circuit Breakers, Surge Protective Devices, Interior Lighting, Nurse Call and Code Blue Systems, Physical Access Control System, Fire Detection and Alarm Systems, Direct-Digital Control System for HVAC, Hydronic Piping)
• Division 23: HVAC (e.g., Common Work Results for HVAC, Noise and Vibration Control, HVAC and Boiler Plant Insulation, Air Terminal Units, HVAC Fans, Motor Controllers, Direct-Digital Control System for HVAC)
• Division 26: Electrical Installations (e.g., Requirements for Electrical Installations, Low-Voltage Electrical Power Conductors and Cables, Grounding and Bonding, Raceway and Boxes, Panelboards, Enclosed Switches and Circuit Breakers, Surge Protective Devices, Lighting Controls)

This document is crucial for bidders as it details the specific technical requirements, materials, installation methods, and standards for various building systems. Understanding these specifications is essential for accurate bidding, proposal preparation, and successful project execution. It outlines the quality, performance, and compliance standards that must be met for the "Renovate Dialysis" project.

Other / Unclassified

This document contains structural calculations and analysis related to the "Renovate Dialysis" project at the Iowa City VA Health Care System. It includes:

• Patient Lift Loading Calculations: Analysis of vertical and lateral/longitudinal impact loads for patient lifts.
• RISA Structural Analysis Reports: Detailed reports from RISA software for various structural components, including:
  • Patient Lift Connections (SK-2, SK-3)
  • Existing Concrete Beam Analysis (SK-4, SK-5, Page 1-15)
  • Detailed member properties, loads, and results for concrete beams and hot-rolled steel.
• Handwritten Calculations: Manual calculations for beam bending (top and bottom reinforcement) and reinforcement details.

This document provides critical structural engineering data that underpins the "Renovate Dialysis" project. Bidders involved in structural work, or those needing to understand the structural implications of the renovation (e.g., for equipment installation, modifications to existing structures, or new construction), will find this information essential for accurate bidding and execution. It details the loads, material properties, and structural analysis results that define the project's structural requirements and constraints.

Form / Attachment / Pricing Sheet

This document contains architectural drawings, including floor plans, elevations, details, and schedules, for the "Renovate Dialysis" project at 601 Highway 6 W, Iowa City, IA. It details the scope of work for renovating the 5th floor of the facility.

• Sheet Index: Provides a comprehensive list of all drawings included in the document set, categorized by discipline (Architectural, Fire Protection, Structural, Hazardous Material, General, Electrical System, Mechanical HVAC, Electrical, Technology, Medical Gas, Plumbing).
• Project Information: Includes project title, location, VA project number, and contact information for consultants.
• Drawings: Detailed plans and elevations for various aspects of the renovation, including demolition plans, life safety plans, infection control and phasing plans, framing plans, and equipment plans.
• Schedules: Includes sheet indexes, opening schedules, and material/room finish schedules.
• Details: Provides specific construction details for various elements such as partitions, doors, windows, and casework.
• General Notes: Outlines project requirements, codes, and standards applicable to the construction.

This document is critical for bidders to understand the full scope of the "Renovate Dialysis" project. It provides detailed information on the existing conditions, proposed renovations, specific requirements for each trade, and critical safety and infection control measures. Bidders must review these drawings to accurately estimate costs, develop a construction schedule, and ensure compliance with all project specifications.

Other / Unclassified

This document is a General Decision Number IA20250068, issued by the U.S. Department of Labor, Wage and Hour Division. It provides prevailing wage rates for various construction classifications in Johnson County, Iowa. The document lists specific job titles (e.g., Boilermaker, Carpenter, Electrician, Painter, Plumber) along with their corresponding hourly rates and fringe benefits. It also includes information on Executive Orders related to paid sick leave and minimum wage for federal contractors, as well as details on how wage determinations are made and how to appeal them.

This document is relevant to bidders as it establishes the minimum wage rates that must be paid to laborers and mechanics employed on construction projects covered by the Davis-Bacon Act. Bidders must use this information to accurately estimate labor costs for their proposals and ensure compliance with federal labor laws. The document also outlines procedures for handling unlisted classifications and appealing wage determinations, which may be important for understanding contract requirements and potential disputes.

Form / Attachment / Pricing Sheet

This document outlines the "basic" privacy training requirements for VA personnel, contractors, volunteers, or others who do not use VA sensitive information or protected health information (PHI) in any form, or who do not have access to VA computer systems containing such information. It details the responsibilities for protecting VA sensitive information (medical, financial, or educational) that may be incidentally or accidentally seen or overheard.

• Defines VA Sensitive Information and Protected Health Information (PHI).
• Explains "Incidental Disclosure" and provides examples.
• Lists safeguards that must be followed to secure VA sensitive information.
• Outlines the six Privacy Laws and Statutes governing VA (FOIA, Privacy Act of 1974, HIPAA, 38 U.S.C. 5701, 38 U.S.C. 7332, 38 U.S.C. 5705).
• Details rules concerning the use and disclosure of protected health information.
• Explains how privacy is enforced, including civil and criminal penalties.
• Includes a section for employee and contractor information to be signed and submitted.

Contractors and their personnel who will not have direct access to VA sensitive information or VA computer systems containing PHI may use this document to satisfy the "basic" privacy training requirement. Personnel with direct access to VA sensitive information or VA computer systems must complete additional specific training (Privacy and HIPAA Focused Training - TMS 10203) and VA Privacy and Information Security Awareness and Rules of Behavior (TMS 10176). This document highlights the critical importance of protecting veteran information and the potential consequences of violations, which is essential for any contractor working with the VA.

Statement of Work (SOW) / Performance Work Statement (PWS)

This document outlines the Records Management Obligations for contractors working with the Iowa City VAHCS, ensuring proper handling and safeguarding of Federal records.

• Contractors must comply with all applicable records management laws, regulations, and NARA policies, including the Federal Records Act and the Privacy Act of 1974.
• All data created for Government use and delivered to or under the control of the Government are considered Federal records and must be managed according to Federal law.
• Contractors are responsible for preventing the alienation or unauthorized destruction of records.
• Any inadvertent or unauthorized disclosures of information, data, or records must be immediately reported.
• Contractors shall not remove material from Government facilities or systems without express written permission.
• Records must be returned to Iowa City VAHCS control or held until otherwise directed when no longer required.
• Destruction of records is prohibited unless in accordance with specific regulations.
• Contractors require Contracting Officer approval before engaging subcontractors who will handle information or records.
• Contractors shall only use Government IT equipment for authorized purposes.
• Contractors shall not create or maintain non-public Iowa City VAHCS information not tied to the contract.
• Contractors shall not retain, use, sell, or disseminate copies of deliverables containing protected information.
• The Iowa City VAHCS owns all rights to data and records produced under the contract.

Not specified in this document.

• Compliance with Federal Records Act, NARA regulations, and Privacy Act of 1974.
• Prevention of record destruction or alienation.
• Reporting of unauthorized disclosures.
• Obtaining Contracting Officer approval for subcontractor relationships involving records.
• Use of Government IT equipment only for authorized purposes.
• Flowdown of these requirements to subcontractors is mandatory.

Statement of Work (SOW) / Performance Work Statement (PWS)

This Statement of Work outlines the requirements for the general construction project "Renovate Dialysis" at the Iowa City VA Medical Center.

• Provide all tools, materials, equipment, and labor for the renovation of approximately 5,000 SF of the existing dialysis clinic.

• The project includes preparing a temporary dialysis clinic before renovating the main clinic space.

• Work involves demolition, construction of new elements, and restoration of existing conditions.

• Specific tasks include:

  • Phase I: Prepare 5 Floor West (Zone 2) for temporary dialysis clinic.
  • Phase II: Demolish 5 Floor South Dialysis (Zone 1).
  • Phase III: Construct enclosure around decontamination unit and remove asbestos.
  • Phase IV: Demolish 5 Floor South elements for new construction.
  • Phase V: Cap and remove piping, replace sanitary pipe.
  • Phase VI: Construct 5 Floor South (Zone 1).
  • Phase VII: Restore 5 Floor West (Zone 2) to pre-existing condition.

• Contractor is responsible for infection control measures, including temporary barriers and maintaining negative air pressure.

• Demolition of equipment and materials not scheduled for reuse.

• Protection of existing conditions not scheduled for demolition.

• Removal and replacement of ceiling tiles only when necessary or damaged.

• Period of Performance: 304 calendar days from the issuance of the Notice to Proceed.

• Location: Iowa City VA Medical Center.

• Work hours are generally normal business hours (8:00 AM - 4:30 PM) Monday-Friday, excluding Federal Holidays. Moderate weekend/after-hours work may be required.

• Shutdowns for electrical, HVAC, chilled water, and fire suppression systems require at least 14 calendar days' written notice to the COR and must be scheduled after normal business hours or during weekends.

• Contractor must coordinate work with the VA COR and VA staff.

• Contractor shall conduct a thorough site visit prior to construction start.

• All designs, drawings, and specifications developed are the sole property of the US Government.

• Change orders must be brought to the attention of the Contracting Officer for negotiation and approval before execution.

• Contractor is responsible for providing their own containers for garbage and debris removal.

• Weekly progress meetings will be held with VA Engineering.

• Weekly project meeting minutes are the responsibility of the general contractor.

• Contract Award: D

• Pre-construction conference: D+7

• Notice to Proceed: D+14

• Construction start: D+30

• Construction completion: D+318

Solicitation / RFP / RFQ

This solicitation is for the construction project "636A8-24-001 Construction-Renovate Dialysis (IC)" at the Iowa City VA Health Care System. The project involves renovating approximately 5,000 SF of the existing dialysis clinic, including initial renovation work to establish a temporary dialysis clinic. The work must be performed in accordance with the provided construction documents, specifications, and drawings.

• General construction services to renovate the dialysis clinic.

• Preparation of a temporary dialysis clinic.

• Renovation of 5,000 SF of the existing dialysis clinic.

• Compliance with all applicable VA, Federal, State, and local codes.

• Contract Type: Firm-fixed price.

• Period of Performance: 10 calendar days for performance to begin after notice to proceed, with a total performance period of 304 calendar days.

• Estimated Value: The magnitude of construction cost is estimated between $5,000,000.00 and $10,000,000.00.

• Submission Method: Bids must be submitted via email to calvin.courtney@va.gov by 2:30 PM (CT) on Wednesday, January 28, 2026.

• Bid Submission Documents: Must include SF 1442 Solicitation, Offer, and Award, acknowledgement of amendments, Price Schedule, and Bid Guarantee.

• Evaluation Criteria: Award will be made to the responsible bidder whose bid is most advantageous to the government, considering only price.

• Key Deadlines:

  • Questions Due: January 9, 2026, by 2:00 PM (CT).
  • Site Visit: Monday, January 5, 2026, at 1:00 PM (CT).
  • Bids Due: January 28, 2026, by 2:30 PM (CT).

• This acquisition is a set-aside for Service Disabled Veteran Owned Small Business (SDVOSB) concerns.

• Offerors must be certified SDVOSBs listed in the SBA certification database.

• Offerors must represent their status as a (1) SDVOSB eligible under VAAR 819.70, (2) small business concern under the assigned NAICS code, and (3) certified SDVOSB listed in the SBA certification database.

• A Limitation on Subcontracting formal certification must be provided with the bid.

• NAICS Code: 236220 (Commercial and Institutional Building Construction) with a $45 Million small business size standard.

• A site visit is scheduled for January 5, 2026. Offerors are urged to inspect the site.

• Technical questions must be submitted via email only.

• Bids must be submitted electronically via email. Late bids may be rejected.

• A bid guarantee is required.

Solicitation / RFP / RFQ

This is a notice for an upcoming Invitation for Bid (IFB) for Project Number 636A8-24-001, "Renovate Dialysis PN," located at the Iowa City VA Medical Center in Iowa City, IA. The Department of Veterans Affairs (VA) intends to award a single, firm fixed-price contract for the renovation of the existing dialysis clinic. The project involves preparing a temporary dialysis clinic and then renovating approximately 5,000 SF of the existing facility.

• Renovation of the existing dialysis clinic space.

• Preparation and operationalization of a temporary dialysis clinic.

• Provision of all necessary tools, materials, equipment, labor, and supervision.

• Construction work must be planned and executed to have no impact on daily operations of the VA Medical Center.

• Contract Type: Firm Fixed-Price.

• Period of Performance: 304 calendar days from the Notice to Proceed (NTP).

• Estimated Magnitude of Construction: $5,000,000.00 to $10,000,000.00.

• The IFB will be issued on or about November 10, 2025.

• Response Date/Time/Zone: December 10, 2025, 13:00 Mountain Time, Denver, USA.

• Further details on site visits and bid due dates will be provided in the IFB.

• The IFB, specifications, drawings, and forms will be available for download on SAM.gov Contract Opportunities.

• This acquisition is a 100% Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside.

• Offerors must represent to the Contracting Officer that they are:

  • An eligible SDVOSB under VAAR 819.70.
  • A small business concern under NAICS code 236220.
  • Certified as an SDVOSB and listed in the SBA certification database.

• Offerors must provide a Limitations of Subcontracting - Certificate of Compliance with their proposal.

• Applicable NAICS Code: 236220 (Commercial and Institutional Building Construction) with a size standard of $45,000,000.00.

• All prospective bidders must have a Unique Entity Identifier (UEI) and be registered and active in SAM.gov.

• All questions must be submitted in writing to calvin.courtney@va.gov. No telephone inquiries will be answered.

• This notice is for informational purposes only and is not a request for bids.