Y1BG--561A4-22-700 EHRM Infrastructure Upgrades Construction - Lyons, NJ VAMC

Statement of Work (SOW) / Performance Work Statement (PWS)

This document specifies the requirements for the furnishing, installation, connection, and testing of secondary unit substations.

• Installation of secondary unit substations, including electrical ratings, components, and physical characteristics.

• Requirements for factory tests, submittals (shop drawings, data, manuals, test reports, certifications), and field tests.

• Specific details on liquid-filled transformers, including features, insulation, impedance, windings, and vacuum fault interrupters.

• Installation procedures for both exterior and interior locations, including concrete slab requirements and grounding.

• Acceptance checks, follow-up verification, temporary heating, and instruction for personnel.

• Substations must meet or exceed National Electrical Code (NEC) requirements and specifications shown on drawings.

• Short circuit current ratings must meet available maximums.

• Temperature rises for insulation systems must not exceed NEMA Standard test values.

• Sound levels must conform to 3 dB below NEMA standards.

• Transformer energy efficiency must comply with 10 CFR Part 431.

• Not explicitly stated in this document, but implies installation at the VANJHCS facility in Lyons, NJ.

• Compliance with various industry standards (ANSI, ASTM, IEEE, NFPA, UL, NEMA, ICC, ACI).

• Use of self-cooled, liquid-filled transformers (auto-transformers not accepted).

• Inclusion of vacuum fault interrupters with specific trip characteristics and electronic controllers.

• Requirements for specific materials, such as copper windings and silicon steel cores.

• Provisions for mechanical interlocks, cleaning, painting, and shipping.

• Detailed requirements for submittals, including shop drawings, data, manuals, test reports, and certifications.

• Specific installation requirements for concrete slabs, anchoring, and grounding.

• Acceptance tests including comparison of nameplate data, physical inspection, functional tests of cooling fans, and verification of electrical connections.

• Training for personnel on maintenance and operation of substations.

Amendment / Modification

This amendment (0003) to solicitation 36C77626R0001 makes the following changes:

• Provides Technical Question Tracker: Includes the technical question tracker with all supporting attachments and VA responses.

• Revises Payment Clause: Removes VAAR 852.232-71 and replaces it with VAAR 852.232-70. The procurement will now adhere to VAAR 852.232-70.

• VAAR 852.232-71 has been removed.

• VAAR 852.232-70 has been added and implemented.

This amendment does not explicitly state a change to the offer receipt deadline. Bidders should ensure they acknowledge this amendment as per the solicitation instructions. The change in the payment clause may impact how contractors structure their payment requests and how payments are processed under the contract.

Solicitation / RFP / RFQ

This document outlines the specifications for Unit Masonry work, which includes concrete masonry unit (CMU) assemblies for exterior and interior walls. It details the materials, installation procedures, and quality control measures required for this scope of work.

• Materials: Specifies requirements for face brick (ASTM C216, Grade SW, Type FBS), building brick (ASTM C62), and concrete masonry units (ASTM C90, load-bearing, hollow and solid, fire-rated). It also details requirements for steel reinforcing bars, joint reinforcement, anchors, ties, and accessories like weeps and joint fillers.
• Installation: Covers general installation procedures, anchorage methods (veneer to framed walls, concrete walls, abutting masonry), reinforcement installation, brickwork, concrete masonry unit installation, expansion and control joints, isolation joints, pointing, and grouting.
• Quality Assurance: Includes requirements for mockups, testing, and adherence to applicable publications from ACI, ASTM, BIA, and AWS.
• Field Quality Control: Mandates water penetration testing for exterior masonry walls.

This document is part of the 100% Construction Documents REV01 for the Electronic Health Records Modernization (EHRM) project at Lyons, NJ. The VA Project No. is 561A4-22-700.

This document does not contain specific submission or evaluation criteria, as it focuses on the technical specifications for the unit masonry work.

No specific eligibility or set-aside information is provided in this document.

• The document references numerous standards and publications that must be complied with.
• It details specific requirements for hot and cold weather construction.
• A construction warranty is required per FAR clause 52.246-21.

Questions & Answers / Clarifications

This document contains responses to contractor questions regarding the Lyons EHRM Infrastructure Upgrades solicitation.

• Procurement Type: The procurement is a Firm Fixed Price (FFP) contract using the Lowest Price Technically Acceptable (LPTA) method.
• Permit Fees: Permit fees are not waived or paid by others; contractors must confirm any waivers or government-paid permits with the Contracting Officer.
• Testing Laboratory Services: These are contractor-provided unless otherwise directed.
• Phasing: The baseline phasing plan (G-020) must be maintained, though concurrent execution may be proposed and approved by the Contracting Officer/Contracting Officer's Representative (CO/COR).
• Commissioning Agent: The VA will hire a third-party commissioning agent under a separate contract; Section 1.1 G of the specifications is incorrect.
• Specifications: Several specifications were confirmed as part of the bid package (02 82 11, 13 05 41, 13 21 33, 08 90 00) or clarified as not required (07 71 00) or located elsewhere (26 05 41). Specification 04 20 00 referencing 09 06 00 is to be disregarded.
• Small Business Set-Aside: The procurement is set aside for general Small Business concerns, not specifically VOSB or SDVOSB. Small Business status will be verified via the SBA Small Business Search (SBS) tool using SAM.gov registration.
• PIV Badging: All personnel require a VA PIV Card. Contractors must begin the PIV process immediately after bond submission.
• Site Visits: No site visits or contact with the site are permitted outside of official site visits. Unauthorized contact risks jeopardizing the procurement.
• Flooring/Partitions/Ceilings: Specific clarifications were provided for flooring in TR rooms (static dissipating vinyl), partition types (A4 typical), and ceiling finishes in various rooms.
• Asbestos Abatement: Specification 02 82 11 is confirmed as part of the bid documents.
• Project Labor Agreement (PLA): A PLA is required and must be submitted after contract award, not with bids.
• Working Hours: Some TR work can occur during normal hours, but work in hallways and occupied spaces requires coordination for after-hours work. 24/7 occupied spaces can be worked on during normal hours.
• ICRA Requirements: ICRA is required in all spaces as outlined on sheets G-30 and G-31.
• Cutover Schedule: Contractors may propose cutover schedules, but final sequencing requires coordination with COR/OI&T, and service must be maintained.
• Cabling Installation: New cabling shall not be floated or staged within active pathways. The VA OI&T is responsible for patching/moving to new cabling. Contractors must coordinate cutover plans with VA OI&T.
• Patch Cords: The contractor is responsible for providing all patch cords.
• Underground Utilities: The contractor is responsible for NJ One Call and private locates.
• Storage: Space for container and inside storage will be determined by the COR after award.
• Parking Lot Blocking: Can be coordinated on a case-by-case basis with the COR in advance.
• Notice to Proceed: Anticipated within 90 calendar days after award.
• Question Due Date: Will not be extended.
• Telecom Outlet Notations: 'WP' indicates Wall Phone, 'WM' indicates Wiremold, a square symbol indicates a power pole, and 'MD' in a circle indicates a Motion Detector.
• Access Control Panels: Locations vary; contractors must engage early with COR and VAPD.
• Conduit Requirements: "Free air" cabling is not allowed; a 5" square box and 1-1/4" Flex conduit are required.
• Fiber Routing: New fiber pathways inside buildings are required. Conduit is required for building-to-building fiber runs. A and B side fiber runs must be separate when passing between buildings. Contractors must field verify existing conduit sizes.
• Excavated Material: Contractor is responsible for geotechnical engineer assessment for suitability for backfill.
• Differing Site Conditions: Contractors must immediately notify the VA; the Contracting Officer will determine if a modification is warranted.
• SSHO: Can dual hat as Superintendent, but QA/QC must be separate.
• Stored Materials: Payment for procured and/or stored materials is at the Contracting Officer's discretion and handled case-by-case.
• Economic Price Adjustment (EPA): FAR 52.216-4 will not be included.
• Buy American Act: Exceptions are detailed in FAR 52.225-12 and FAR 52.225-11. Non-compliant items must be listed in the offer.
• Tariffs: Escalation for tariffs will not be considered; all escalation should be factored into the FFP bid.
• Project Schedules: The revised Master Specification 01 32 16.15 will be included via addendum 1.
• VAAR Clause: VAAR 852.232-71 is replaced by VAAR 852.232-70.

These clarifications address numerous technical, logistical, and contractual points, providing essential details for bidders to refine their proposals. No changes to the due date for questions were made.

Other / Unclassified

This document, "General Commissioning Requirements" (Section 01 91 00), outlines the procedures and responsibilities for the construction phase commissioning process for the Electronic Health Records Modernization (EHRM) Infrastructure Upgrades project at VANJHCS, Lyons, NJ. It details the objectives, scope, roles, and responsibilities of the commissioning team, including the Commissioning Agent (CxA), Contractor, and VA representatives, across various phases: Construction, Acceptance, and Warranty.

Key aspects covered include:

• The definition and purpose of commissioning.
• Contractual relationships and communication protocols.
• Systems to be commissioned (e.g., Building Exterior Closure, Roofing, Fire Suppression, Plumbing, HVAC, Electrical, Communications, Electronic Safety and Security).
• Detailed roles and responsibilities for each phase (Construction, Acceptance, Warranty).
• Procedures for startup, initial checkout, pre-functional checklists, and functional performance testing.
• Requirements for test equipment, trending, alarms, and documentation.
• Procedures for handling deficiencies, nonconformance, and approvals.
• Guidelines for deferred testing and operation and maintenance training.

This document is crucial for bidders as it defines the comprehensive commissioning process that will be applied to the project's systems and equipment. Understanding these requirements will help bidders:

• Identify the scope of work related to commissioning and its integration into the overall construction schedule.
• Understand the roles and responsibilities of their own personnel (e.g., Commissioning Manager, Commissioning Representatives) in the commissioning process.
• Anticipate the documentation, testing, and training requirements they will need to fulfill.
• Recognize the importance of coordination with the Commissioning Agent and VA throughout the project lifecycle.
• Factor in the time and resources needed for commissioning activities, including startup, testing, and training, when preparing their bids.

Form / Attachment / Pricing Sheet

This document is the Table of Contents for the "100% CONSTRUCTION DOCUMENTS" for the "Electronic Health Records Modernization (EHRM)" project at the VA facility in Lyons, NJ. It outlines the structure and content of the full construction documentation set.

The Table of Contents is organized into Divisions (e.g., Division 00 - Special Sections, Division 01 - General Requirements, Division 02 - Existing Conditions, etc.) and further broken down into specific specification sections with corresponding page counts. It covers a wide range of construction disciplines including concrete, masonry, metals, wood, thermal and moisture protection, openings, finishes, specialties, fire suppression, plumbing, HVAC, electrical, communications, electronic safety and security, earthwork, exterior improvements, and utilities.

This document is crucial for bidders as it provides a comprehensive overview of all technical specifications and requirements for the construction project. It allows potential bidders to quickly assess the scope of work, identify specific areas of interest or expertise, and understand the detailed requirements for each construction discipline. The page counts for each section can also help in estimating the effort required for proposal preparation and understanding the complexity of the project.

Other / Unclassified

This document is a sign-in sheet for a site visit conducted on January 30, 2026, for the EHRM Infrastructure Upgrades Construction project at the Lyons VAMC. It records the names, company affiliations, titles, email addresses, and phone numbers of attendees.

This document is relevant to potential bidders as it indicates which companies and individuals attended the site visit. This can provide insight into the level of interest in the opportunity and potentially identify competitors or partners who are actively engaged with the project.

Amendment / Modification

This amendment (0002) to solicitation 36C77626R0001 makes the following changes:

• Provides the completed site visit sign-in sheet.

• Removes FAR 52.223-20 and FAR 52.223-21 from the solicitation.

• The solicitation itself is modified.

• FAR clauses 52.223-20 and 52.223-21 are removed.

• Bidders should note the removal of the specified FAR clauses.

• The site visit sign-in sheet is now available as an attachment.

• The amendment does not extend the hour and date specified for receipt of offers.

Form / Attachment / Pricing Sheet

This document provides instructions and details for an organized site visit related to the EHRM Infrastructure Upgrades Construction Project in Lyons, NJ.

• Date and Time: Friday, January 30, 2026, at 9:00 AM EST.
• Meeting Location: Lyons VAMC, 151 Knollcroft Road, Lyons, NJ 07939, Building 10, Second Floor Conference Room.
• Site Map: Includes a map indicating Building 10 and visitor parking.

This information is crucial for potential bidders who need to attend the site visit to gain a better understanding of the project site and its conditions. Attendance may be mandatory or highly recommended for proposal submission.

Amendment / Modification

This amendment (0001) updates Attachment 9 - Site Visit Instructions.

• Attachment 9 - Site Visit Instructions

• The date for the site visit has been corrected from Wednesday, January 30, 2026, to Friday, January 30, 2026. All other terms and conditions of the original solicitation remain unchanged.

Form / Attachment / Pricing Sheet

This document comprises the 100% Construction Documents for the EHRM Infrastructure Upgrades project at the VA New Jersey Healthcare System in Lyons, NJ. It includes detailed drawings and specifications essential for the construction phase. Additionally, it contains specific "Building 57 Panel Schedules" and "Building 135 Panel Schedules" detailing electrical panel configurations, voltage, phase, amperage, SCCR, AFC, and circuit load details (KVA, Amps/Phase, Phase) for each circuit.

• Construction Documents: Comprehensive architectural, electrical, mechanical, and structural drawings.
• Specifications: Detailed technical requirements and standards.
• Project Information: VA Contract Number (36C77624C0006), VA Project Number (561A4-22-700), construction document date (01-21-2025).
• Electrical Panel Schedules: Specific details for Buildings 57 and 135, including panel identification, electrical specifications, and circuit load information.
• Notes: Instructions for "NEW WORK IN BOLD" regarding new breakers or specific breaker types.
• Applicable Codes and Manuals: Numerous codes, regulations, and VA design manuals.
• Project Team: Owner, architect/engineer of record, and consultants.

This document is critical for bidders to understand the full scope of work, technical specifications, and project requirements for the EHRM Infrastructure Upgrades. The electrical panel schedules are essential for accurately planning and quoting electrical work, ensuring compatibility with existing infrastructure, and accounting for any necessary breaker provisions or load calculations. Accurate review of these documents is vital for precise bidding and successful project execution.

Solicitation / RFP / RFQ

This solicitation is a Request for Proposal (RFP) for the EHRM Infrastructure Upgrades Construction project at the Lyons VA Medical Center in Lyons, NJ. The project involves selective demolition, general construction, alterations, and the completion of various building systems (Architectural, Fire Protection, Plumbing, Mechanical, Electrical, Telecommunication, Fire Alarm). The magnitude of construction is estimated between $20,000,000 and $50,000,000.

• Comprehensive construction services including demolition, alterations, and system upgrades.

• Provision of all necessary tools, equipment, materials, labor, supervision, and personnel.

• Adherence to attached Specifications and Drawings.

• Completion of the entire project within 960 calendar days after receiving the Notice to Proceed.

• Contract Type: Firm-Fixed-Price.

• Performance Period: 960 calendar days from Notice to Proceed.

• Proposals are due by 13:00 EST on March 5, 2026.

• Submission is via email to Donald.Marsh2@va.gov and Samuel.Cornwell@va.gov in three volumes (Technical, Price, Administrative) as searchable PDFs, not exceeding 20MB per email (max 3 emails).

• Evaluation Method: Lowest Price Technically Acceptable (LPTA).

• Key Deadlines: Questions due by February 6, 2026.

• This procurement is a 100% set-aside for Small Business concerns.

• Offerors must be certified as small businesses by the SBA at the time of proposal submission and award.

• A mandatory site visit is scheduled; details are in Attachment 9.

• Bid Guarantee required (SF 24), not less than 20% of proposal price, not to exceed $3,000,000.

• Performance and Payment Bonds (SF 25 and SF 25A) will be required upon award.

• Solicitation documents are available at sam.gov. Offerors are responsible for obtaining and acknowledging all amendments.

Form / Attachment / Pricing Sheet

This document, "Key Subcontractors Information," is a form that bidders must complete to provide details about their past performance on relevant contracts. It is intended to gather information on the bidder's experience and performance, which will be evaluated in accordance with the Request for Proposal instructions.

• Offeror Information: Name, role (prime or subcontractor).
• Contract Details: Contract number, project number, NAICS code, project title, location, contracting officer/POC, owner's project manager/POC.
• Contract Performance Dates: Award date, notice to proceed date, original scheduled completion date, actual completion date.
• Contract Financials: Award amount, final amount.
• Contract Modifications: Number of change orders and reasons for changes.
• Safety: OSHA citations (if applicable).
• Subcontractor Information: List of major subcontractors with POC and phone numbers.
• Narrative: Detailed description of work performed and its relevance (very relevant, relevant, or somewhat relevant).

Bidders must complete this form for each contract/project submitted to demonstrate their experience and performance. The information provided, particularly the narrative describing the relevance of past work, will be crucial for the evaluation of their proposal. A separate, completed form is required for each project described.

Form / Attachment / Pricing Sheet

This document provides instructions and details for an organized site visit related to the EHRM Infrastructure Upgrades Construction Project in Lyons, NJ.

• Event: Site Visit
• Project: EHRM Infrastructure Upgrades Construction Project
• Location: Lyons VAMC, 151 Knollcroft Road, Lyons, NJ 07939
• Date and Time: Wednesday, January 30, 2026, at 9:00 AM EST
• Meeting Point: Building 10, Second Floor Conference Room
• Included: A site map indicating the meeting location and visitor parking.

This document is crucial for potential bidders to understand the physical site of the construction project. Attending the site visit is often essential for gaining a comprehensive understanding of the project's scope and requirements, which can impact proposal development and bidding strategy.

Form / Attachment / Pricing Sheet

This document is a General Decision Number (GDN) for wage determinations in Somerset County, New Jersey, for building construction projects. It specifies the prevailing wage rates and fringe benefits for various labor classifications.

• Geographic Area: Somerset County, New Jersey, with specific delineations for certain townships and boroughs.
• Construction Type: Building construction projects (excluding single-family homes and apartments up to 4 stories).
• Labor Classifications: Includes rates for Asbestos Worker/Heat & Frost Insulator, Bricklayer, Cement Mason, Tile Finisher/Setter, Carpenter (Scaffold Builder, Acoustical Ceiling, Drywall Hanging, Formwork), Millwright, Electrician (including low voltage wiring, cable splicer), Elevator Mechanic, Power Equipment Operators (Groups 1-5), Ironworkers, Laborer (Mason Tender, Asphalt Shoveler, etc.), Drywall Finisher/Taper, Painter, Glazier, Plasterer, Plumber/Pipefitter, Roofer, Sprinkler Fitter, Sheet Metal Worker, and Truck Drivers.
• Rates and Fringes: Provides hourly wage rates and corresponding fringe benefit rates for each classification.
• Special Conditions: Includes additional pay for specific tasks such as work on high stacks, motorized lifts, hazardous waste removal, and working at heights.
• Paid Holidays and Vacation: Outlines paid holiday schedules and vacation pay credit based on years of service.
• Executive Orders: References Executive Order 13706 (Paid Sick Leave) and Executive Order 13658 (minimum wage for federal contractors).

This document is crucial for bidders as it establishes the minimum wage rates and fringe benefits that must be paid to laborers and mechanics employed on the construction project. Bidders must ensure their cost proposals and labor practices comply with these prevailing wage requirements to be considered compliant with federal regulations.

Form / Attachment / Pricing Sheet

This document is a Pre-Construction Risk Assessment (PCRA) template used by the VHA for Construction, Renovation, and Maintenance activities. It establishes minimum requirements for categorizing activity types and safety risks to determine necessary precautions to prevent impact on patients, employees, and contractors. It must be used in conjunction with the VHA Infection Control Risk Assessment (ICRA) if required.

• Activity Details: Includes location (Lyons), activity name/number (561A4-22-700 EHRM Infrastructure Upgrades), and project start/completion dates (02/02/2026 - 12/31/2029).
• Activity Type: Categorized as 'Large Scale' construction, renovation, or maintenance, defined by work exceeding 6 months in duration and where patients/employees are not in the area until completion.
• Control Measures: Outlines specific control measures for different activity types, including general inspection/upkeep, small-scale, and large-scale work. For 'Large Scale' activities, this includes excavation safety, dust control, pollution prevention, dig safe, crane lift plans, fall protection, and confined entry plans.
• Affected Adjacent Area Assessment: Requires coordination with adjacent areas to prevent disruption, with specific plans for vacant, non-continuously occupied, and continuously occupied areas.
• Permit Information: Includes a unique permit number, project manager, contact information, contractor details, and a section for required Activity Hazard Analyses and Control Plans.
• ICRA Requirement: Indicates whether an Infection Control Risk Assessment is required, with signatures from Infection Prevention and Control, Project Manager, Safety Office, and Construction Safety Committee.

This document outlines the safety and risk management protocols that will be in place for the EHRM Infrastructure Upgrades project. Bidders should review the defined 'Large Scale' activity type and associated control measures, including safety plans, hazard analyses, and coordination requirements with adjacent areas. Understanding these requirements is crucial for planning and executing work safely and in compliance with VHA standards. The document also highlights the need for coordination with Infection Control and the potential for an ICRA.

Form / Attachment / Pricing Sheet

This document is a Geotechnical Engineering Report for the EHRM Infrastructure Upgrades project. It provides findings from subsurface exploration and geotechnical recommendations for earthwork, foundation design, floor slab construction, and pavement design.

• Project Description: Details the proposed MCR building, including its footprint, construction type, and finished floor elevation.
• Site Conditions: Describes the project location, topography, geology, and existing improvements.
• Geotechnical Characterization: Outlines the subsurface soil and bedrock conditions, including identified model layers (Loose Sand, Silt, Weathered Bedrock).
• Seismic Site Class: Classifies the site as Seismic Site Class C.
• Earthwork Recommendations: Covers site preparation, subgrade preparation, bedrock excavation, excavation safety, reuse of materials, imported fill, structural fill placement, grading, drainage, and construction considerations.
• Shallow Foundations: Provides design parameters for shallow foundations, including allowable bearing pressure, minimum foundation dimensions, and resistance values.
• Floor Slabs: Details design parameters for floor slabs, including support requirements and modulus of subgrade reaction.
• Pavements: Outlines pavement design parameters for asphaltic concrete (AC) and Portland Cement Concrete (PCC), including subgrade preparation and section thicknesses.
• Attachments: Includes Exploration and Testing Procedures, Site Location and Exploration Plans, Exploration and Laboratory Results (Boring Logs, Grain Size Distribution), and Supporting Information (General Notes, Unified Soil Classification System, Rock Classification).

This report is crucial for bidders to understand the subsurface conditions and geotechnical requirements for the project. It informs decisions regarding site preparation, foundation design, structural considerations, and pavement construction, directly impacting project planning, execution, and cost estimation.

Form / Attachment / Pricing Sheet

This document comprises the "100% Construction Documents" for the EHRM Infrastructure Upgrades project at the VA New Jersey Healthcare System, located at 151 Knollcroft Road, Lyons, NJ. It includes a comprehensive set of architectural and engineering drawings detailing site plans, utility improvements, building renovations, demolition work, exterior wall construction, roof details, interior framing, and extensive fire protection systems.

• Site & Utilities: Includes site plans, paving, grading, and detailed plans for proposed water, sanitary sewer, storm sewer, electrical duct banks, and fiber optic infrastructure.
• Building Work: Covers demolition plans, renovation plans (floor plans, reflected ceiling plans), partition types, door schedules, finish schedules, and exterior wall/roof/interior framing details.
• Fire Protection: Details firestopping requirements for wall penetrations, temporary fire suppression, fire suppression systems for telecommunication spaces and the main computer room (MCR), including hazard classifications and design criteria. Also includes fire alarm and sprinkler system scope.
• Structural: Outlines design loads, foundation requirements, concrete, reinforcing steel, masonry walls, structural steel, and steel decking specifications.
• Mechanical & Plumbing: Includes HVAC plans, controls, schedules for various equipment (CRAC units, VRF systems), duct/pipe insulation, and domestic water/waste vent diagrams.
• General & Specific Notes: Contains applicable codes, regulations, VA design manuals, infection control details, hazardous material information, and specific instructions for firestopping, ceiling restoration, and coordination.

This document is critical for bidders as it provides the complete technical specifications, design details, and scope of work for the EHRM Infrastructure Upgrades. Bidders must thoroughly review these construction documents to accurately estimate costs, develop a construction schedule, and ensure compliance with all project requirements, including site preparation, utility work, building renovations, finishes, and stringent fire protection and safety standards. The detailed drawings and specifications are essential for accurate bidding and project execution.

Form / Attachment / Pricing Sheet

This document comprises multiple attachments related to an asbestos and lead inspection report for the Lyons VA Medical Center, as part of the EHRM project. It includes the main inspection report, a Chain of Custody form for sample tracking, and an Asbestos Fiber Analysis report.

• Asbestos and Lead Inspection Report: Details findings from a limited inspection of rooms impacted by the EHRM project at Lyons VA Medical Center. Materials with greater than 1% asbestos and paints/coatings with greater than 1 mg/cm² lead were identified and require removal by licensed/certified personnel prior to renovation.
• Chain of Custody Form: Used by International Asbestos Testing Laboratories (IATL) to track bulk samples for asbestos analysis (PLM method). It lists client information, project details, sample numbers, and chain of custody records.
• Asbestos Fiber Analysis Report: Conducted by Eurofins EPK, this report details the results of PLM testing on various samples from specified buildings (GDM of Oregon Bldg 135, 141, East Guard Shack). Results for asbestos constituents were "Not Detected" in these specific samples.

This information is critical for bidders as it identifies potential hazardous materials (asbestos and lead paint) within the project area. Bidders must account for the presence, location, and quantity of these materials in their proposals, project plans, and cost estimates. The findings directly impact the scope of work, safety protocols, abatement strategies, and overall project execution, requiring removal by licensed contractors before renovation activities can commence. While the Chain of Custody form is administrative, the inspection and analysis reports provide essential data on hazardous materials.

Form / Attachment / Pricing Sheet

This document is Volume 1, Divisions 00 through 21 of the construction documents for the Electronic Health Record Modernization (EHRM) Infrastructure Upgrades project at the VA Lyons, NJ Medical Center. It contains the Table of Contents for Volume 1, outlining the various divisions and sections of the specifications.

• Division 00 - Special Sections: Includes Table of Contents and List of Drawing Sheets.
• Division 01 - General Requirements: Covers general requirements, project schedules, safety, quality control, waste management, and other administrative aspects.
• Division 02 – Existing Conditions: Details selective demolition, asbestos abatement, and lead paint removal.
• Divisions 03 through 32: Cover various construction trades and systems including Concrete, Masonry, Metals, Wood, Plastics, Composites, Thermal and Moisture Protection, Openings, Finishes, Specialties, Equipment, Conveying Equipment, Fire Suppression, Plumbing, HVAC, Integrated Automation, Electrical, Telecommunications, Electronic Safety and Security, Earthwork, Exterior Improvements, and Utilities.

This document serves as a comprehensive index to the construction specifications for Volume 1. Bidders must review this Table of Contents to understand the scope of work, identify relevant sections for their trade, and ensure they are referencing the correct specifications for the project. It is crucial for understanding the full scope of the EHRM Infrastructure Upgrades project at the VA Lyons, NJ Medical Center.

Solicitation / RFP / RFQ

This is a solicitation for a design-bid-build minor construction project (#561A4-22-700) for EHRM Infrastructure Upgrades at the Lyons VA Medical Center (VAMC) in Lyons, NJ. The Department of Veterans Affairs (VA) intends to award a single firm-fixed-price contract.

• Comprehensive renovations including selective demolition, installation, testing, and certification of Cat6a cabling throughout all buildings.

• Improvements to normal and emergency electrical distribution systems (power distribution panels, lighting, controls, receptacles, grounding-bonding, UPS, etc.).

• Upgrades to physical security and access control systems.

• Finishes for new or altered rooms (walls, floors, ceilings).

• All work must be completed in strict accordance with the SOW, drawings, and specifications.

• Contractor must provide all tools, materials, labor, quality assurance, and supervision.

• Proactive safety and infection control compliance is required.

• Contract Type: Firm-Fixed-Price

• Period of Performance: Approximately 960 calendar days from Notice to Proceed.

• Magnitude of Construction: $20,000,000 to $50,000,000.

• The solicitation will be issued as a Request for Proposals (RFP) under FAR Part 15.

• Evaluation will be based on Lowest Price Technically Acceptable (LPTA) procedures.

• Response Date/Time/Zone: December 8, 2025, 13:00 Eastern Time, New York, USA.

• All questions must be submitted in writing via email to Samuel.Cornwell@va.gov. Telephone calls will not be accepted.

• This solicitation is a total Small Business set-aside.

• NAICS Code: 236220 (Commercial and Institutional Building Construction) with a size standard of $45.0 million.

• Offers from other than Small Business concerns will not be considered.

• The solicitation is anticipated to be issued in Mid-December 2025.

• The contracting office is Program Contracting Activity Central (PCAC), located in Independence, OH.

• The Place of Performance is Lyons VA Medical Center, 151 Knollcroft Road, Lyons, NJ 07939, USA.