Design-Bid-Build, USCG Offshore Patrol Cutters (OPC) Homeport Pier, Naval Station Newport, Newport RI

Amendment / Modification

This amendment (0004) to Solicitation N4008526R0001 for the USCG Offshore Patrol Cutters (OPC) Homeport Pier project makes the following changes:

• Proposal Due Date Extension: The proposal due date has been extended from June 9, 2026, to June 15, 2026, at 2:00 PM EDT. No additional Pre-Proposal Inquiry (PPI) responses will be accepted.

• New Attachments Provided:

  • Continuation sheet for drawings and specifications.
  • Updated Attachment K - WD RI20260001 dated 05-18-2026.
  • Attachment U - Appendix A - Pier 1 Extension 1968 (attached separately).
  • Attachment V - Pier 1 - Amendment 004 Drawings (attached separately).
  • PPI Responses (enclosed).

• Drawings: Several drawings have been revised or incorporated, including:

  • C-102 (Utility Plan - Pier 1 Landside)
  • C-202 (Utility Profiles)
  • C-505 (Site Details)
  • SD001 (Structural Demolition Notes)
  • SD101 (Overall Structural Demolition Plan)
  • SD102 (Pier 1 Demolition Plan)
  • S-110 through S-115 (Framing Plans)
  • S-504 (Concrete Pile Cap Details)
  • S-517 (Precast Manhole Details)
  • Specific changes include revised keynotes, dimensions, bent counts, and the addition of details for electrical manholes, separation walls, beam elevations, and manhole sections.

• Section 00 00 00 - Procurement and Contracting Requirements: The response due date has been updated.

• Section 00 73 00 - Supplementary Conditions: The Amendment 0004 Continuation Page has been added.

• The proposal deadline has been extended to June 15, 2026.

• Bidders must acknowledge this amendment. The document includes updated drawings and specifications that may impact proposal preparation.

Forms / Attachments / Pricing Sheets

This document is a General Decision for wage rates, specifically "RI20260001" effective 05/18/2026. It lists prevailing wage rates and fringe benefits for various construction crafts and laborers in Rhode Island.

• Geographic Area: Rhode Island Counties of Bristol, Kent, Newport, Providence, and Washington.
• Construction Types: Building, Heavy and Highway, including Marine Construction Projects.
• Classifications: Includes rates for Hazardous Material Handler, Asbestos Worker/Insulator, Boilermaker, Bricklayer, Stonemason, Pointer, Caulker & Cleaner, Marble Setter, Terrazzo Worker & Tile Setter, Marble, Tile & Terrazzo Finisher, Piledriver, Welder, Carpenter, Millwright, Teledata System Installer, Electrician, Elevator Mechanic, Power Equipment Operator (various groups), Ironworker, Laborer (various groups), Painter, Glazier, Cement Mason/Concrete Finisher, Plasterer, Plumbers and Pipefitters, Roofer, Sprinkler Fitter, and Sheet Metal Worker.
• Rates and Fringes: Provides hourly rates and fringe benefit amounts for each classification.
• Footnotes and Special Conditions: Includes specific conditions, additional pay for certain work (e.g., hazardous material, tunnels, swing stages, boom lengths), and holiday pay.

This document is crucial for any bidder on a federal or federally-funded construction project in the specified geographic area. It establishes the minimum wage and fringe benefit rates that must be paid to laborers and mechanics employed on the project, as required by the Davis-Bacon Act and related prevailing wage laws. Bidders must use these rates to accurately calculate their labor costs and ensure compliance with federal regulations.

Form / Attachment / Pricing Sheet

This document contains detailed engineering drawings and specifications for the "Pier No. 1 Extension" project. It serves as a critical reference for contractors to understand the structural, electrical, and architectural requirements for the construction and modification of Pier No. 1.

• Structural Drawings: Detail the pier's construction, including plans, sections, elevations, framing, pile details, and connections to existing structures.
• Electrical Drawings: Outline power outlet locations, cabling diagrams, switchgear, transformers, and connections for the pier extension and associated buildings.
• Architectural Drawings: Show details for additions to existing buildings, including structural elements, roofing, and utility hoods.
• General Notes & Design Criteria: Provide essential information on loads, materials, concrete specifications, pile bearing capacities, and welding requirements.
• Boring Logs: Indicate subsurface soil conditions relevant to foundation design.

This comprehensive set of drawings is essential for bidders to accurately estimate costs, develop construction methodologies, and ensure compliance with all technical specifications. It defines the scope of work, materials, and construction methods required for the pier extension and related facilities.

Amendment / Modification

This document, Amendment 004, revises previously issued drawings and specifications for the USCG OCR Homeport Initiative OPC Pier project. Key changes include:

• Drawing Revisions: Several drawings have been updated, including:
  • C-202 (Utility Profiles - Sheet 2 of 2) updated on 05/15/2026.
  • SD101 (Structural Demolition Notes) updated on 05/15/2026.
  • SD102 (Pier 1 Demolition Plan) updated on 05/15/2026.
  • S-110 (Framing Plan - Sheet 1 of 7) updated on 05/15/2026.
  • S-111 (Framing Plan - Sheet 2 of 7) updated on 05/15/2026.
  • S-112 (Framing Plan - Sheet 3 of 7) updated on 05/15/2026.
  • S-113 (Framing Plan - Sheet 4 of 7) updated on 05/15/2026.
  • S-114 (Framing Plan - Sheet 5 of 7) updated on 05/15/2026.
  • S-115 (Framing Plan - Sheet 6 of 7) updated on 05/15/2026.
  • S-504 (Concrete Pile Cap Details) updated on 05/15/2026.
  • S-517 (Precast Manhole Details) updated on 05/15/2026.
• Previous Amendments Incorporated: Amendments 002 and 003 are also noted as incorporated into this revision.

All listed drawings have been affected by this amendment.

Bidders should ensure they are using the latest revised drawings and specifications for their proposals. The specific impact on proposal deadlines or submission requirements is not detailed in this amendment, but it is critical to use the most current documentation.

Form / Attachment / Pricing Sheet

This document, Appendix F, titled "Sediment Sampling Report, Geoarcheological Report and Historic Soil/Groundwater Sampling Results," provides the results of sediment sampling and analysis conducted to support the proposed Project's RIDEM/CRMC Section 401 Water Quality Certification application and to evaluate likely dredged material disposal options. The analytical results will also support the proposed Project's RIDEM/CRMC dredge permit application. It also contains quality control data and laboratory analytical results for soil samples collected from the Naval Station Newport for the USGS OPC PIER 1 project.

• Project Description: Details the USCG OPC Pier project at NAVSTA Newport, RI, including demolition of existing Pier 1 and construction of a new 1,000 ft long pier.
• Sampling Objectives: To collect physical and chemical data from sediment to support dredge permit and Water Quality Certification applications, and to screen sediment against upland disposal requirements.
• Sampling Methodology: Used a vibracore system, collecting samples from mudline to 2 feet below mudline, and 2-feet below mudline to an anticipated disturbance depth of six feet, at 16 locations.
• Analytical Methods: Performed analyses for grain size, % moisture, VOCs, SVOCs, TPH, PCBs, metals, ignitability, pH, flashpoint, reactive cyanide, reactive sulfide, paint filter liquid, asbestos, tributyltin, and PFAS.
• Results: Key findings include arsenic and zinc exceeding RIDEM/CRMC screening levels in multiple samples, and asbestos detected in one sample (2% chrysotile by weight) and trace amounts in seven others. No contaminants of concern were detected above the TCLP screening level, indicating sediments can be classified as non-hazardous waste under RCRA.
• Quality Control: Includes method blank analysis, lab control sample analysis, matrix spike analysis, and lab duplicate analysis for various parameters. Sample receipt and container information, including cooler details and custody seals, are also provided.
• Laboratory Analytical Results: Detailed results for TCLP Metals, Total Metals, Ignitability, Solids, General Chemistry, Grain Size Analysis, Volatile Organics, TCLP Volatiles, Semivolatiles, TCLP Semivolatiles, Petroleum Hydrocarbons, PCBs, TCLP Pesticides, Pesticides, and TCLP Herbicides for soil samples.

This document is crucial for bidders to understand the environmental conditions of the project area, specifically the composition and potential hazards of the sediment to be disturbed and dredged. This information is essential for planning disposal options, assessing environmental risks, and ensuring compliance with regulatory requirements. Bidders need to be aware of the presence of asbestos and other contaminants, as this will impact disposal costs and procedures. The detailed breakdown of contaminants and their concentrations is essential for developing accurate project plans and cost estimates for environmental remediation, site assessment, or construction projects at or near Naval Station Newport.

Justification and Approval (J&A) for Other Than Full and Open Competition

This document justifies the use of brand-name specifications for a compressed air system from manufacturer Kaeser for solicitation N4008526R0001. This solicitation is for a Design-Bid-Build project for the USCG Offshore Patrol Cutters (OPC) Homeport Pier at Naval Station Newport, RI.

The overall project involves demolishing an existing pier and constructing a new one, along with a new bulkhead, laydown area, parking, and various utilities, including the compressed air system.

• A compressed air system, including all compressors, driers, and accessories, to be provided by Kaeser.

• The system must be fully installed within a shipping container from Kaeser.

• The system will supply air compressor needs to all utility connections along the new Pier 1.

• The acquisition will be an unrestricted, full and open, stand-alone construction solicitation.

• The estimated value of the overall construction work is approximately [redacted], with [redacted] estimated for the compressed air system.

• Funding is from FY22 Major Acquisition Systems Infrastructure (MASI) and FY25 One, Big Beautiful Bill Act (OBBBA).

• The work is required to be completed within 918 calendar days after contract award.

• A solicitation notice will be publicized on SAM.gov.

• The Contracting Officer will determine price fairness and reasonableness using methods outlined in RFO Part 15.

• This is an unrestricted solicitation.

• The project requires a fully installed, outdoor compressed air system due to the lack of central utility.

• Using a single manufacturer (Kaeser) is essential to limit potential construction issues and change orders, providing a cost-effective solution.

• Kaeser has a dedicated facility for building the enclosure, ensuring quality control and troubleshooting.

• This is the only product that provides a fully assembled and shipped compressed air system from one manufacturer.

• A sources sought notice was published on SAM.gov on March 11, 2026, detailing the requirements.

• No responses were received by the response date of March 26, 2026.

• NAVFAC Mid-Atlantic has no current plans to compete future contracts for this type of supply/service.

• Future feasibility will be assessed if another potential source emerges.

Form / Attachment / Pricing Sheet

This document is a Bid Price Schedule (UCCG OPC Pier Price Proposal Form REV 2) that bidders must complete and submit as part of their proposal. It details the pricing structure for the USCG OPC Pier project at Naval Station Newport, RI.

• BASE PRICE (Line Item 0001): Covers the total cost for the entire work, including demolition of existing Pier 1, construction of landside area, new Bulkhead S45S, and new OPC Pier 1. This excludes Option Items.
• Detailed Line Items (0001A - 0001Z): Specific pricing for various components of the project, including:
  • Construction of the new OPC Pier and associated site work.
  • Dredging and disposal of materials (ACM and non-ACM).
  • Furnishing and installation of various pile types (steel pipe, HP piles, polymeric fender piles).
  • Demolition and disposal of debris, including hazardous materials (ACM, PCBs, lead).
  • Construction of Bulkhead S45S.
  • Testing for piles.
  • Water sampling, testing, treatment, and discharge.
• Option Items (0002, 0003): Pricing for a Compressed Air System and additional concrete pavement for the laydown area.
• Quantities: Some quantities are marked with an asterisk (*) indicating they are estimated and bidders will only be paid for actual work performed. Adjustments may be made based on actual quantities.

Bidders must provide firm fixed prices for Line Items 0001-0003. Failure to enter a price for any line item will result in proposal rejection. The unit price will govern if there is a discrepancy between unit price and extended total. The total proposed price for Base and Option Items will be used for award evaluation. Additional bonding may be required if Option Items are exercised.

Form / Attachment / Pricing Sheet

This document is Appendix D of the "Stormwater Management Plan for USCG OCR Homeport Initiative OPC Pier" and is titled "Environmental Concurrence and Project Permit Documents (With Placeholders)". It serves as a placeholder for environmental concurrence and project permit documentation related to the USCG OCR Homeport Initiative OPC Pier project at Naval Station Newport, Rhode Island.

• The document is primarily a placeholder, indicating that specific environmental concurrence and project permit documents are to be included.
• It is part of a larger Stormwater Management Plan, specifically Appendix D.

This document is an appendix to the Stormwater Management Plan and does not contain direct requirements or solicitations for bidders. It indicates that environmental and permit documentation will be provided, which may be relevant for understanding project constraints and regulatory compliance.

Amendment / Modification

This amendment (0003) incorporates the following:

• Drawings and Specifications: Provides a continuation sheet for drawings and specifications. Revises and incorporates numerous contract drawings, including updates to site details, framing plans, deck plans, utility trench details, and electrical site plans. Specific changes include adding datum planes, railroad coordination notes, details for stone surface restoration, dimensions for wet wells, and revisions to concrete plank and pipe support details.
• Attachments: Provides Word copies for several attachments (Construction Experience Project Data Sheet, Past Performance Questionnaire, Historical Small Business Utilization, SB Participation Commitment Document), an updated Price Proposal Form (REV 2), and additional specifications appendices (Soil GW Sed Sampling Reports, Appendix D with placeholders, Electrical Shore Ties CSTO testing requirements).
• Clauses and Provisions: Updates various clauses and provisions, including modifications to "Instructions to Offerors-Competitive Acquisition," "Information Regarding Responsibility Matters," and "Violation of Arms Control Treaties or Agreements-Certification." Adds several FAR clauses related to construction contracts, hazardous materials, and small business concerns. Deletes specific FAR clauses including "Instructions to Offerors-Competitive Acquisition (Alternate I)," "Individual Surety-Pledge of Assets," "Prohibition of Assignment of Claims," and "Termination for Convenience of the Government (Fixed-Price)."
• Justification & Approvals (J&As): Includes five J&As related to compressed air systems, shore tie receptacles, line insulation monitors, and sanitary pumps.
• Pre-proposal Inquiry Responses: Provides responses to pre-proposal inquiries, clarifying insurance costs, the use of specific keynotes on drawings, pile testing requirements, and the sequence for pile procurement.

This amendment affects numerous sections of the original solicitation, including specifications, contract drawings, and various clauses and provisions. Specific details are provided within the amendment regarding changes to individual drawings and the incorporation of new or revised clauses.

Offerors should review all updated attachments, drawings, clauses, and provisions carefully. The amendment provides clarifications and updates that may impact proposal preparation and the understanding of contract requirements. The pre-proposal inquiry responses offer specific clarifications relevant to bidding.

Form / Attachment / Pricing Sheet

This document, "Attachment C - Construction Experience Project Data Sheet," is a form designed for offerors to provide detailed information about their past construction projects. It is intended to help the government assess the offeror's relevant experience for the opportunity.

• Offeror Information: Requires firm name, address, UEI, CAGE code, and point of contact details.
• Role in Project: Specifies whether the offeror acted as a prime contractor, subcontractor, joint venture, or other, and the percentage of work performed.
• Contract Details: Includes contract number, title, location, award and completion dates.
• Project Type: Categorizes the work performed (e.g., New Construction, Renovation, Repair, Alteration).
• Contract Type: Details the contract structure (e.g., Firm-Fixed Price, Cost/Time and Material, Design-Build, Design-Bid-Build).
• Project Description: Requires a detailed description of the project and its relevancy to the current RFP requirements, including unique features, square footage, and construction methods. For Design-Build projects, a description of the design effort is also required.
• Self-Performed Work: Asks for a description of the work the offeror's firm directly performed.
• Financials: Includes fields for Award Amount and Final Price.

Bidders must complete this form accurately to demonstrate their qualifications and relevant construction experience. The information provided will be crucial for the government's evaluation of the offeror's capability to successfully perform the work outlined in the solicitation. Failure to provide complete and relevant information may impact the evaluation of the proposal.

Form / Attachment / Pricing Sheet

This document, Attachment D, is the NAVFAC/USACE Past Performance Questionnaire (PPQ-0). It is to be utilized for all evaluations requiring a Past Performance Questionnaire. Bidders are instructed to use this form if a completed Contractor Performance Assessment Reporting System (CPARS) evaluation is not available for a project included in Factor 1 for construction and design experience.

• Contractor Information: Firm Name, CAGE Code, Address, UEI, Phone Number, Email Address, Point of Contact.
• Work Performed As: Prime Contractor, Sub Contractor, Joint Venture, or Other.
• Contract Information: Contract Number, Delivery/Task Order Number, Contract Type, Contract Title, Contract Location, Award Date, Contract Completion Date, Original Contract Price, Final Contract Price.
• Project Description: Complexity, relevance to the submission project.
• Client Information: Name, Title, Phone Number, Email Address, Client's role in the project.
• Questionnaire Completion: Date completed, Client's Signature.
• Adjective Ratings: Definitions and rating scales (Exceptional, Very Good, Satisfactory, Marginal, Unsatisfactory, Not Applicable) for Quality, Schedule/Timeliness, Customer Satisfaction, Management/Personnel/Labor, Cost/Financial Management, Safety/Security, and General performance.

This questionnaire must be completed by the client for each project the bidder includes in their proposal for Factor 1 Corporate Experience, if a CPARS evaluation is not available. Bidders should ensure correct client contact information is provided and follow up to ensure timely submission. If a completed PPQ cannot be obtained before the proposal closing date, the bidder should submit the first page of the PPQ with contract and client information. Offerors should not submit a PPQ when a completed CPARS is available. Completed PPQs should be submitted with the proposal, or may be submitted directly to the Government's Point of Contact (Kristy Gerrek, kristy.l.gerrek.civ@us.navy.mil) prior to the proposal closing date.

Form / Attachment / Pricing Sheet

This document, Attachment E, is a mandatory form for all offerors (both large and small businesses) to provide historical small business utilization and achievements. It is used for the evaluation of Factor 5, Small Business Utilization and Participation, and must be completed for each project submitted under Factor 1, Corporate Experience.

• Project Details: For each project, provide contract number, project title, offeror's business size, performance role (prime, subcontractor, JV), and whether a subcontracting plan was required.
• Actual vs. Goal Columns: For each project, bidders must complete the "ACTUAL" column detailing dollar values and percentages subcontracted for various categories (Small Business, Large Business, SDB, WOSB, HUBZone, VOSB, SDVOSB). The "GOAL" column is for entering established goals, if applicable. If no goals were established for a task order, only the "ACTUAL" column needs completion.
• Unmet Goals: If a goal was unmet, a detailed explanation is required in the "TO BE COMPLETED AS REQUIRED" section.
• No Small Business Achievement: If a project had zero small business subcontracting, an explanation is required.
• Definitions: Clarifies "Total Project Dollar Value," "Total Self-Performed Value," and "Total Subcontract Value."

Accurate and complete submission of this form is crucial for the evaluation of the Small Business Utilization factor. Offerors must use the provided format; alternative formats will not be evaluated. Bidders should carefully document their historical subcontracting performance, paying close attention to unmet goals and providing necessary explanations.

Form / Attachment / Pricing Sheet

This document, Attachment F, is the Small Business Participation Commitment Document (SBPCD). All offerors, regardless of size (large or small business), must complete this form to provide supporting information for the evaluation of Factor 5, Small Business Utilization and Participation. This is the sole form that will be evaluated for determining the offeror's small business participation commitment. Offeror-created forms or formats will not be evaluated.

• Offeror Information: Prime contractor size (Large Business or Small Business) and applicable socioeconomic categories (SDB, WOSB, EDWOSB, HUBZone SB, VOSB, SDVOSB, or None).
• Subcontracting Breakdown: Total contract value (TCV), value of self-performed work, and value of subcontracted work.
• Small Business Participation Table: Requires dollar value and percentage of TCV to be subcontracted to various small business categories (Total SB, SDB, WOSB, HUBZone, VOSB, SDVOSB). The minimum total small business subcontracting requirement is 20%.
• Identification of Subcontractors: A table to list specific small businesses with whom firm commitments are in place, including their category, products/services, and nature of commitment (e.g., teaming agreement, JV, mentor-protégé, letter of commitment).
• Explanations/Rationales: Sections to provide detailed explanations if the minimum 20% small business participation is not met, or if no subcontractors with firm commitments are identified. Large business offerors not intending to subcontract must also provide an explanation.

This form is critical for demonstrating compliance with small business utilization goals. Bidders must accurately complete all sections, detailing their proposed subcontracting plan with small businesses. Failure to meet the minimum 20% commitment or provide adequate explanations may impact the evaluation of Factor 5.

Form / Attachment / Pricing Sheet

This document, "Attachment R - 26 08 00 - Electrical Shore Ties CSTO (Rev B) - Section 2.4.6 Testing," details the installation and acceptance testing procedures for electrical shore ties.

• Installation Requirements: Specifies the use of single hole type lugs with stud adapters, and requires compression lugs to be specifically designed for finely stranded cable with oxide inhibitor applied. Prohibits the use of Allen screws or mechanical clamps for terminations.
• Acceptance Testing: All tests must be performed in the presence of a Coast Guard inspector or COR. A written report of test results is required within one week of completion.
• Equipment Inspection: Prior to installation, new electrical equipment must be inspected for damage.
• Connection Checks: Requires checking and tightening accessible electrical connections to manufacturer's torque specifications, verifying grounding connections, and ensuring switches and circuit breakers operate freely.
• Insulation Testing: Mandates insulation tests (phase to ground and phase to phase) with specific resistance requirements (minimum 1000 kilohm). Details procedures for insulation resistance tests of cables, transformers, lighting fixtures, and heaters using a megohmmeter, including test voltages based on operating voltage and temperature correction to 25°C. Minimum acceptable insulation resistance values are provided in Table 2-2.
• Conductor Resistance Test: Required for paralleled power conductors to ensure even load current division.
• Operability and Clearance Checks: Requires cycling new components for operability and verifying adequate servicing access and interference-free operation for newly installed equipment.
• Enclosure Tightness Tests: Specifies a water leakage test for outdoor penetrations and closures.
• Electrical System Acceptance Testing: To be accomplished at power mounds using a resistive/reactive load bank.
• Cable Identification: Requires installation of new cable identification tags with color coding for power conductors as indicated.

This document outlines critical testing and installation requirements that bidders must adhere to for the electrical shore ties. Understanding these procedures is essential for successful project execution and acceptance. It details the specific tests, standards, and reporting required, which will impact labor, materials, and scheduling for the proposed work.

Amendment / Modification

This document is Amendment 003, dated May 5, 2026, to the "Attachment S - Pier 1 - Amendment 003 Drawings.pdf".

This amendment pertains to the drawings associated with Pier 1.

No impact on proposal deadlines or submission requirements is indicated by this amendment.

Form / Attachment / Pricing Sheet

This document contains "Existing Pier 1 Drawings" which provide detailed plans and specifications for the existing conditions of Pier 1 at Coddington Cove, Newport, R.I. These drawings are intended to inform bidders about the current state of the pier's structure, including its sheet piling, concrete deck, and associated components.

• Plan Views: Detailed layouts of Pier 1, showing the arrangement of sheet piling, concrete decks, pile caps, and existing repair elements.
• Sections and Details: Cross-sections and specific detail drawings illustrating construction methods, materials, and existing conditions of various components such as sheet piling, concrete piles, and timber facing.
• Structural Notes: Information regarding concrete strength, reinforcing steel, and other construction material specifications.
• Repair Information: Details on previous repairs, including types of repairs, materials used, and locations.
• Dimensions and Elevations: Specific measurements, elevations relative to Mean Low Water (MLW), and other critical data for understanding the pier's physical characteristics.

These drawings are crucial for potential bidders to accurately assess the scope of work, identify existing conditions, and develop precise proposals for any related repair or construction opportunities at Pier 1. They provide the foundational information needed to understand the existing infrastructure and any potential challenges or requirements for future work.

Other / Unclassified

This document is a Class Justification and Approval (J&A) for the use of other than full and open competition for Facilities Related Control Systems (FRCS), specifically Advanced Metering Infrastructure (AMI) electric meters, front-end interface, and software. It authorizes the use of brand-name commercial equipment from Schneider Electric (PowerLogic Ion Meters and SCADAPack Smart RTUs) and EIG (Shark 270 and Shark 250).

This document explains why the government is restricting competition for certain equipment related to the MIDLANT AMI Network. It details the need for standardization and interoperability with existing systems to maintain cybersecurity, reduce costs, and ensure operational efficiency. While this document itself is not a solicitation, it provides critical context for any future solicitations related to the MIDLANT AMI Network, indicating a preference for specific manufacturers and product lines due to these justification reasons. Bidders interested in opportunities involving the MIDLANT AMI Network should be aware of these specified manufacturers and the rationale behind the sole-source justification.

Justification and Approval (J&A)

This document justifies and approves the use of other than full and open competition for a specific requirement related to the USCG Offshore Patrol Cutters (OPC) Homeport Pier project at Naval Station Newport, RI. The contracting activity is Naval Facilities Engineering Systems Command, Mid-Atlantic (NAVFAC MIDLANT).

• The solicitation (N4008526R0001) is for a Design-Bid-Build construction project to demolish an existing pier and construct a new pier, bulkhead, laydown area, parking, and utilities.

• A specific requirement within this solicitation is for a Communications Shore-Tie Receptacle.

• The brand name specification for this receptacle is the RussellStoll SKWR12XG Receptacle.

• This brand name item is required to meet USCG C4&IT Shore Tie Cable Standards (Rev 1.4) for landside shore-tie communications receptacles to provide shipboard connectivity.

• The estimated value of the construction solicitation is approximately [REDACTED].

• The estimated value for the Communications Shore-Tie Receptacle is approximately [REDACTED].

• Funding is provided by FY22 Major Acquisition Systems Infrastructure (MASI) and FY25 One, Big Beautiful Bill Act (OBBBA).

• The work is required to be completed within 918 calendar days after contract award.

• The solicitation will be publicized on SAM.gov.

• A sources sought notice was previously published on SAM.gov on March 11, 2026, detailing the requirements, but no responses were received.

• The Contracting Officer will determine if the price is fair and reasonable prior to contract award using various analysis techniques.

• This acquisition is being solicited as an unrestricted full and open, stand-alone construction solicitation.

• The statutory authority for this action is 10 U.S.C. 3204(a)(1), permitting the use of limited suppliers when essential to agency requirements.

• NAVFAC Mid-Atlantic has no plans at this time to compete future contracts for these specific supplies/services, but will assess feasibility if another potential source emerges.

Justification and Approval (J&A) for Other Than Full and Open Competition

This document justifies the use of brand-name specifications for a Ground Detection System – Line Insulation Monitor (LIM) for the USCG Offshore Patrol Cutters (OPC) Homeport Pier project in Newport, RI. The project involves demolishing an existing pier and constructing a new pier, bulkhead, and associated utilities.

• The solicitation requires a Ground Detection System – Line Insulation Monitor (LIM).

• The system must meet brand-name specifications for the Bender ISOMETER iso685.

• The LIM monitors insulation resistance for ungrounded delta 450V, three-phase power systems, as required by USCG Electrical Shore Ties Configuration Standard Technical Order (CSTO) and National Electrical Code (NEC) Article 250.21.

• The system alarms if a ground fault occurs and allows for proactive replacement of at-risk cabling.

• The overall construction project is estimated to be completed within 918 calendar days after contract award.

• Funding is provided by FY22 Major Acquisition Systems Infrastructure (MASI) and FY25 One, Big Beautiful Bill Act (OBBBA).

• A sources sought notice was published on March 11, 2026, but no responses were received.

• A solicitation notice will be publicized on SAM.gov.

• The Contracting Officer will determine if the price is fair and reasonable prior to award using various comparison techniques.

• This acquisition is being solicited as an unrestricted full and open competition.

• The use of brand-name specifications is justified because the USCG CSTO specifically references the Bender series of ground fault monitoring systems, with the ISOMETER iso685 being the required product.

• NAVFAC Mid-Atlantic has no current plans to compete future contracts for these specific supplies/services.

Justification and Approval (J&A)

This document justifies the use of other than full and open competition for a solicitation (N4008526R0001) related to the USCG Offshore Patrol Cutters (OPC) Homeport Pier project at Naval Station Newport, RI. The project involves demolishing an existing pier and constructing a new one, along with associated utilities and infrastructure.

• The solicitation includes requirements for a Duplex Direct Inline Pump System (Overwatch OW21-4VV) with brand name specifications for the manufacturer Overwatch.

• This system is required to service the OPC's sanitary discharge at the pier utility connections, specifically addressing issues with a gravity sanitary main that was prone to corrosion and failure.

• The proposed solution involves direct inline duplex pumps to overcome back pressure and provide a design flow of 150 gallons per minute at each service station.

• The estimated value of the overall construction work is approximately [redacted].

• The project will be funded by FY22 Major Acquisition Systems Infrastructure (MASI) and FY25 One, Big Beautiful Bill Act (OBBBA) funding.

• The work is required to be completed within 918 calendar days after contract award.

• This acquisition will be solicited as an unrestricted full and open, stand-alone construction solicitation.

• A sources sought notice was published on SAM.gov on March 11, 2026, seeking commercially available products, but no responses were received.

• A solicitation notice will be publicized on SAM.gov.

• The Contracting Officer will determine if the price is fair and reasonable prior to award using various comparison techniques.

• The solicitation will be unrestricted.

• The use of brand name specifications for the Duplex Direct Inline Pump System is justified due to specific design requirements determined by the USCG OPC Integrated Logistics Support Plan (ILSP) Facilities Requirements.

• NAVFAC Mid-Atlantic has no current plans to compete future contracts for these types of supplies/services, but will reassess if a potential source emerges.

Amendment / Modification

This amendment (0002) to Solicitation N4008526R0001 for the USCG Offshore Patrol Cutters (OPC) Homeport Pier project makes the following key changes:

• Proposal Due Date Extended: The deadline for proposal submissions has been extended from May 19, 2026, to June 09, 2026.
• Updated Attachments: Several attachments have been updated or added, including:
  • Updated Attachment G - Individual SB Subcontracting Plan
  • Updated Attachment H - UCCG OPC Pier Price Proposal Form REV 1
  • Attachment M - Schedule of Special Inspections
  • Attachment N - Statement of Special Inspections
  • Attachment O - OPC Pier 1 - Amendment 002 Revised Drawings
• Revised Drawings: Numerous contract drawings have been revised to incorporate changes related to site conditions, structural elements, utility plans, electrical site plans, and demolition plans. Key revisions include changes to:
  • Deck drain sizes (increased from 8 to 10 inches).
  • Dimensions and configurations of various structures, including concrete pads and bulkhead details.
  • Pipe sizes and elevations.
  • Details for backflow preventer systems and manholes.
  • Clarifications on demolition limits and materials.
• Specification Updates: Several specification sections have been modified:
  • Section 01 14 00: Replaced reference to "Letter of Authorization from NOAA Fisheries" with "Incidental Harassment Authorizations (IHAs) and IHA application from National Marine Fisheries Service."
  • Section 01 35 40 00 20: Added information regarding the Marine Mammal Observation and Acoustic Monitoring Plan.
  • Section 01 45 35: Added "Statement of Special Inspections" and "Schedule of Special Inspections" attachments.
  • Section 01 57 19: Increased the incidental mitigation fee from $53,000 to $59,000 and provided detailed specifications for a wooden table with an acrylic hood.
  • Section 02 61 13: Updated HAZWOPER training requirements for personnel handling soil, groundwater, and sediments.
• Pre-proposal Inquiry Responses: Responses to several pre-proposal inquiries are included, addressing topics such as:
  • Clarification on project experience thresholds.
  • CMMC Level requirements.
  • Project Labor Agreements.
  • Proposal format and page limitations.
  • Clarifications on specific drawings and specifications.
  • Confirmation of agencies for mitigation fees.
  • Details on duct bank installation and railroad track restoration.
  • Clarification on the use of the existing pier for construction operations.
  • Details regarding ground grids and excavation.
  • Confirmation of pier dimensions and associated unit price items.
  • Clarification on the scope of the compressed air system pricing option.
  • Information on laydown areas and weather considerations.
  • Confirmation of manhole diameters and pipe connections.
  • Risk Assessment Code (RAC) for the project.
  • Incidental Harassment Authorizations (IHAs) and NOAA Fisheries authorization.
  • Newport Naval Station's MS4 permit requirements.

This amendment affects the proposal due date, numerous contract drawings, various specification sections, and provides updated attachments and responses to pre-proposal inquiries.

Bidders must note the extended proposal due date. All changes detailed in this amendment, including revised drawings and specifications, must be incorporated into their proposals. Updated attachments should be reviewed for accuracy and completeness.

Amendment / Modification

This document is Amendment 002, dated April 23, 2026, which revises previously issued drawings.

• The "Amendment 002" notation appears on multiple drawing sheets, indicating revisions to the original drawings.

This amendment primarily consists of revised drawings and does not appear to alter proposal deadlines or submission requirements based on the provided information.

Form / Attachment / Pricing Sheet

This document is a Statement of Special Inspections for the USCG OPC Pier Project located at NAVSTA Newport, RI. It outlines the requirements for special inspections related to seismic and lateral force resisting systems, as well as designated seismic systems (DSS).

• Seismic Design Category: E
• Risk Category: III
• Special Inspector of Record (SIOR): Required. The contractor must provide SIOR name and contact information prior to construction start.
• Lateral Force Resisting System (LFRS): Identifies vertical (Pier Piles to Piles Caps) and horizontal (Pier deck system) LFRS elements requiring inspection.
• Designated Seismic Systems (DSS): Applies to this project. Includes nonstructural components with an importance factor of 1.5 and specific project conditions related to life-safety or hazardous substance containment after an earthquake.
• Final Walk-Down Inspection: Required for DSS, performed by the Registered Design Professional in Responsible Charge.
• Documentation: Requires collection of manufacturer Certificates of Compliance for DSS, which become part of the final project O&M Manual.
• Schedule of Special Inspections: The template must be completed, printed, and appended to this statement.

This document details critical inspection and compliance requirements that bidders must understand and plan for. It specifies the need for a Special Inspector of Record (SIOR) and outlines the inspection protocols for LFRS and DSS. Bidders should note the requirements for documentation, including Certificates of Compliance for DSS, and the need to complete and append the Schedule of Special Inspections.

Form / Attachment / Pricing Sheet

This document is Attachment G, an Individual Small Business Subcontracting Plan template. It is designed to be consistent with FAR 19.109 and FAR clause 52.219-9. This plan is to be submitted by other than small businesses (large businesses) as part of their bid or offer.

• Goals: Requires the establishment of goals for subcontracting to various categories of small businesses (Small Business (SB), Historically Underutilized Business Zone (HUBZone) SB, Women-Owned Small Business (WOSB), Small Disadvantaged Business (SDB), Veteran-Owned Small Business (VOSB), Service-Disabled Veteran-Owned Small Business (SDVOSB), AbilityOne, Alaskan Native Corporations & Indian Tribes).
• Subcontracted Products/Services: Requires identification of products/services planned for subcontracting to large businesses and small businesses, with specific commitments.
• Development Methods: Requires explanation of how subcontracting goals were developed and how potential sources were identified.
• Program Administration: Outlines the responsibilities of the individual administering the subcontracting program.
• Reporting: Details requirements for submitting Individual Subcontract Report (ISR) and Summary Subcontract Report (SSR) via SAM.gov.
• Record Keeping: Specifies the types of records to be maintained to document compliance.

This document is crucial for large business bidders as it outlines the mandatory requirements for developing and submitting a subcontracting plan. Bidders must understand these requirements to ensure their proposals are compliant. It details the specific small business categories for subcontracting, the methods for identifying and soliciting these businesses, and the reporting obligations. Failure to submit an acceptable plan may lead to delays or rejection of a bid/offer.

Form / Attachment / Pricing Sheet

This document is the Bid Price Schedule for the USCG OCR Homeport Initiative OPC Pier project at Newport Naval Station. It outlines the various line items for which bidders must provide pricing.

• BASE PRICE (Line Item 0001): Covers the entire work for the OPC Pier, including demolition of existing Pier 1, construction of landside area and Bulkhead S45S, and construction of the new OPC Pier 1. This excludes work provided as Option Items.
• Specific Line Items (0001A - 0001Z): Detail unit prices for various components and tasks, including:
  • Construction of the new OPC Pier and associated site work.
  • Furnishing and installation of different types of steel pipe piles (36" diameter, HP 14x102", HP 10x42", 30" diameter, polymeric fender piles).
  • Work related to steel pipe pile/casing pipe obstruction.
  • Demolition, removal, and disposal of debris and various materials (e.g., soil, asbestos-containing materials, PCB-impacted materials, mercury-containing thermostats, lead).
  • Construction of Bulkhead S45S.
  • "In lieu" fee for potential Eel Grass damage.
  • Dredging and dredge disposal.
• Option Items (0002, 0003): Include pricing for a Compressed Air System and additional costs for cast-in-place concrete pavement.
• General Bid Notes: Provide instructions on award evaluation, contract duration, handling of estimated quantities, payment for piling, evaluation of options, unbalanced offers, and requirements for pricing all line items.

This document is critical for bidders as it defines the specific work items and quantities for which they must submit pricing. Bidders must carefully review each line item, understand the scope of work included and excluded, and provide accurate unit prices and extended totals. Failure to price any line item will result in proposal rejection. The general bid notes also provide important context regarding evaluation criteria and potential contract adjustments.

Form / Attachment / Pricing Sheet

This document, "Schedule of Special Inspections for UFGS 01 45 35," outlines the required special inspections for various construction activities, referencing the 2024 International Building Code (IBC) and other relevant standards (e.g., AISC, AWS, ACI). It serves as a checklist for contractors to ensure compliance with inspection requirements.

• Inspection Definitions: Defines terms like PERFORM, OBSERVE, DOCUMENT, CONTINUOUS, and PERIODIC to clarify the nature of inspections.
• Seismic Design Category: Requires identification of the project's Seismic Design Category.
• Contractor Responsibility: States that the Contractor is responsible for performing all inspections.
• Detailed Inspection Tasks: Breaks down inspections by construction type:
  • Structural Steel (Welding, Bolting, Nondestructive Testing, Other Steel Inspections)
  • Structural Concrete Construction
  • Geotechnical (Soils Inspection, Driven Deep Foundation Elements)
• Inspection Types: Specifies whether tasks require PERFORM (direct action), OBSERVE (random monitoring), DOCUMENT (reporting), CONTINUOUS (ongoing monitoring), or PERIODIC (intermittent inspection).
• Compliance References: Cites specific IBC sections, AISC standards, and other codes for each inspection task.

This document is critical for bidders to understand the quality assurance and inspection requirements associated with the construction work. It details the specific checks and verifications that will be performed on materials, workmanship, and processes throughout the project. Bidders must factor these inspection requirements into their project planning, scheduling, and cost estimations to ensure compliance and successful project execution.

Form / Attachment / Pricing Sheet

This document is a Site Visit Log for the "DESIGN-BID-BUILD, USCG OFFSHORE PATROL CUTTERS (OPC) HOMEPORT PIER, NAVAL STATION NEWPORT, NEWPORT RI" project. It records the attendance of individuals from various companies who participated in the site visit.

• Site Visit Date: 07 April 2026
• Time: 1000
• Proposal Due Date: 19 May 2026
• Time: 1400
• The log includes columns for Name, Activity/Company, Title, Phone #, Email, and Signature of attendees.
• Attendees represent a mix of government personnel (NAVFAC) and contractors involved in estimating, project management, and other roles.

This log confirms attendance at the mandatory or optional site visit. Bidders should review this list to see which companies and individuals were present, which may provide insight into the competitive landscape or potential teaming partners. It also reiterates the proposal due date and time.

Amendment / Modification

This amendment (0001) to solicitation N4008526R0001 modifies the original solicitation dated March 19, 2026, for the Design-Bid-Build USCG Offshore Patrol Cutters (OPC) Homeport Pier project at Naval Station Newport, RI.

Specifically, this amendment:

• Provides an updated Attachment F - SB Participation Commitment Document (attached separately).

• Provides Attachment L - Site Visit Log (attached separately).

• Section 00 73 00 - Supplementary Conditions: This section now includes Attachment L - Site Visit Log and the updated Attachment F - SB Participation Commitment Document.

This amendment does not explicitly state a change to proposal deadlines or submission requirements. However, bidders must ensure they are using the updated Attachment F and acknowledge the inclusion of Attachment L.

Form / Attachment / Pricing Sheet

This document, "Attachment F - Small Business Participation Commitment Document (SBPCD)", is a mandatory form for all offerors (both large and small businesses) responding to the solicitation. It is used to provide supporting information for the evaluation of Factor 5, Small Business Utilization and Participation. This is the sole form that will be evaluated to determine the offeror's small business participation commitment. Information provided in any other format or on a different form will not be evaluated.

• Offeror Information: Requires the offeror's name and address.
• Prime Contractor Size: Offerors must indicate if they are a Large Business (LB) or Small Business (SB). If an SB, they must check all applicable socioeconomic categories (SDB, WOSB, EDWOSB, HUBZone SB, VOSB, SDVOSB) or select "None".
• Subcontracting Breakdown: Requires the total contract value (TCV), the value of work self-performed by the prime, and the total value of work to be subcontracted.
• Small Business Participation Table: Details the dollar value and percentage of the TCV for Total Small Business (including all SB socio-economic categories and work self-performed as a SB). It also requires specific breakdowns for SDB, WOSB, HUBZone, VOSB, and SDVOSB. The minimum total small business subcontracting requirement is 20%. If this minimum is not met, a detailed explanation is required.
• Firm Commitments Table: For identified subcontractors, this table requires the Company Name, Small Business Category(ies), Products/Services, and Nature of Commitment (e.g., written teaming agreement, joint venture, mentor-protégé, signed letter of commitment).
• Explanation/Rationale: If no subcontractors are identified with firm commitments, or if a large business offeror does not intend to subcontract, a detailed explanation is required.

This document is critical for bidders to understand and document their commitment to small business participation. Failure to complete this form correctly or meet the minimum 20% small business participation requirement (unless a detailed explanation is provided) will impact the evaluation of their proposal under Factor 5. Offerors must carefully calculate and document their proposed subcontracting values and identify any firm commitments with small businesses.

Solicitation / RFP / RFQ

This solicitation is for a Design-Bid-Build project to demolish an existing US Navy pier and construct a new pier for four Offshore Patrol Cutters (OPCs) at Naval Station Newport, Rhode Island. The project also includes constructing a new bulkhead, laydown area, parking, and associated utilities.

• Demolition of an existing pier (1,570 ft long x 100 ft wide).

• Construction of a new pier (1,000 ft long x 80 ft wide).

• Construction of a new bulkhead (360 ft long).

• Associated infrastructure including laydown area, parking, stormwater management, fire/potable water, electrical, telecommunications, and compressed air utilities.

• The acquisition is being solicited on an unrestricted basis with full and open competition.

• Includes CMMC Level 1 (Self) requirements.

• Considered a "Large-scale Construction Project" requiring a signed Project Labor Agreement.

• Contract type: Firm Fixed Price (FFP).

• Period of Performance: 15 calendar days for commencement after award, and 918 calendar days for completion.

• Estimated Magnitude: Between $100,000,000 to $250,000,000.

• NAICS Code: 237990 with a size standard of $45,000,000.

• Proposals are due by 02:00 PM (EST) on 19 May 2026.

• Offers must be submitted electronically via PIEE.

• Evaluation will be based on Price and five non-price factors: Corporate Experience, Management Approach and Schedule, Safety, Past Performance, and Small Business Utilization and Participation.

• The tradeoff process will be used, with award made to the responsible offeror whose offer represents the best value.

• A site visit is scheduled for 07 April 2026 at 1000 EST.

• Unrestricted with full and open competition.

• Small business subcontracting plan (SBSP) is required for other than small businesses.

• Minimum small business participation requirement is 20% of the total contract value.

• All correspondence regarding this solicitation should be directed via email to Kristy Gerrek at kristy.l.gerrek.civ@us.navy.mil.

• A bid bond (SF-24) in the amount of 20% of the total project bid price or $3M, whichever is less, is required.

• Offerors must be registered in SAM.gov.

• Defense Priorities Allocation System (DPAS) Priority Rating: DO-C2.

Form / Attachment / Pricing Sheet

This document is Attachment A, the Pre-Proposal Inquiry Submission Form, for Solicitation N4008526R0001. It is intended for potential bidders to submit questions regarding the Design-Bid-Build, USCG Offshore Patrol Cutters (OPC) Homeport Pier, Naval Station Newport, Newport RI opportunity.

• The form includes fields for 'Submitted By', 'Date Submitted', 'Reference', 'Question', 'Page', 'Section', and 'Paragraph'.
• Bidders are instructed to use this form to submit their inquiries.

This form is crucial for bidders who have questions about the solicitation. It provides the official method for submitting inquiries, ensuring that questions are logged and can be addressed by the government. The fields indicate the specific information required to submit a clear and actionable question, referencing specific parts of the solicitation document.

Form / Attachment / Pricing Sheet

This document is a Vendor Registration Guide for the Procurement Integrated Enterprise Environment (PIEE) platform. It provides step-by-step instructions for vendors to self-register for a PIEE user account and add roles, specifically the 'Proposal Manager' or 'Proposal View Only' roles for the PIEE Solicitation Module.

• New User Registration: Covers creating a new PIEE account, selecting the 'Vendor' user type, entering User ID, Password, and CAPTCHA, setting up security questions, completing User Profile and Supervisor/Company Information, selecting roles (SOL-Solicitation with Proposal Manager or Proposal View Only), providing justification, and verifying registration details.
• Existing User Role Addition: Details how existing users can log in, navigate to 'My Account', select 'Add Additional Roles', verify profile information, and follow steps similar to new user role selection.
• Roles and Actions: Explains the 'Proposal Manager' role is required to submit offers, while 'Proposal View Only' allows viewing offers. It also outlines available actions and menu items for each role.
• Support Information: Provides links and contact details for Getting Started, Account Support, and Technical Support.

This guide is crucial for any bidder intending to respond to solicitations posted on the PIEE platform. It outlines the necessary steps to create an account and obtain the required roles (Proposal Manager) to submit an offer. Understanding these registration procedures and role requirements is essential for timely and successful participation in the solicitation process.

Form / Attachment / Pricing Sheet

This document is Attachment G, the "Individual Small Business Subcontracting Plan" template. It is designed to be consistent with FAR 19.704 and FAR clause 52.219-9. This template is to be submitted by entities other than small businesses (large businesses) as part of their bid or offer.

• The plan requires the contractor to outline their subcontracting goals for various categories of small businesses, including Small Business (SB), Small Disadvantaged Business (SDB), Women-Owned Small Business (WOSB), Historically Underutilized Business Zone (HUBZone) Small Businesses, Veteran-Owned Small Businesses (VOSB), and Service-Disabled Veteran-Owned Small Businesses (SDVOSB).
• It also requires details on planned subcontracting to Alaskan Native Corporations (ANCs) and Indian Tribes, and AbilityOne associated nonprofit agencies.
• The plan includes sections for detailing the total contract value, total subcontracted amount, and the breakdown of subcontracted dollars by business category.
• It requires the identification of principal products and/or services planned for subcontracting.
• The document also outlines the methods used to develop subcontracting goals, including outreach efforts and the use of SAM.gov.
• Specific requirements for reporting, record maintenance, and good faith efforts are detailed.

This document is crucial for large business bidders as it outlines the mandatory requirements for their subcontracting plan. Bidders must understand these requirements to accurately complete and submit their subcontracting plan as part of their proposal. Failure to include the essential information may lead to delays or rejection of a bid/offer.

Form / Attachment / Pricing Sheet

This document, "Attachment C - Construction Experience Project Data Sheet," is a form required for bidders to provide detailed information about their relevant construction experience. It is used to assess a bidder's qualifications and past performance related to the opportunity.

• Project Identification: Allows selection of up to five construction projects (CON #1-5) and specifies if the experience is for an Offeror, Joint-Venture, or Other.
• Firm Information: Requires firm name, address, phone number, UEI Number, Cage Code, and Point of Contact details.
• Role in Project: Bidders must specify if they acted as Prime Contractor, Sub Contractor, Joint Venture, or Other, and the percentage of work performed.
• Contract Details: Includes Contract Number, Title, Location, Award Date, and Completion Date.
• Type of Work: Categorizes the work performed (New Construction, Renovation, Repair, Alteration).
• Type of Contract/Task Order: Specifies if the contract was Firm-Fixed Price, Cost/Time and Material, or Other.
• Construction Project Details: For Design-Build or Design-Bid-Build projects, bidders must provide the Award Amount, Final Price, and identify the Lead Design Firm if applicable.
• Project Description & Relevancy: Requires a detailed description of the project and its relevancy to the current RFP requirements, including unique features, square footage, and construction methods. For design-build, a description of the design effort is needed.
• Self-Performed Work: A section to detail the work the firm performed themselves.
• Other Information: A general field for additional relevant details.

Bidders must complete this form accurately and thoroughly to demonstrate their capability and experience relevant to the solicitation. The information provided will be crucial for the government's evaluation of the bidder's qualifications. Failure to provide complete and accurate information may impact the evaluation of the proposal.

Form / Attachment / Pricing Sheet

This document, Attachment D, is the NAVFAC Form Past Performance Questionnaire (PPQ). It is to be utilized for all evaluations requiring a PPQ. The PPQ is provided for offerors or their team members to submit to clients for each project included in Factor 1 for Corporate Experience, when a completed Contractor Performance Assessment Reporting System (CPARS) evaluation is not available.

• Contractor Information: Firm Name, Address, Phone, Email, CAGE Code, UEI, Point of Contact.
• Work Performed As: Details on whether the firm acted as Prime Contractor, Sub Contractor, Joint Venture, or Other, and the percentage of work performed.
• Contract Information: Contract Number, Delivery/Task Order Number, Contract Type, Contract Title, Contract Location, Award Date, Contract Completion Date, Actual Completion Date, Original and Final Contract Price.
• Project Description: Relevance of the project to the current submission, including similar equipment, requirements, and conditions.
• Client Information: Client Name, Title, Phone, Email, and their role in the project.
• Questionnaire Completion Date and Client Signature.
• Adjective Ratings: A detailed rating system (Exceptional, Very Good, Satisfactory, Marginal, Unsatisfactory, Not Applicable) with definitions for evaluating contractor performance across Quality, Schedule/Timeliness, Customer Satisfaction, Management/Personnel/Labor, Cost/Financial Management, Safety/Security, and General categories.

This form is crucial for bidders to gather past performance data from clients. It outlines the specific information required to complete the questionnaire and how it should be submitted. Bidders must ensure they obtain completed PPQs from clients for projects where CPARS are not available, or complete the first page if a full PPQ cannot be obtained before the proposal closing date. The detailed rating criteria will help bidders understand the government's expectations for past performance.

Form / Attachment / Pricing Sheet

This document, "Attachment E - Historical Small Business Utilization," is a form to be completed by all offerors (both large and small businesses). Its purpose is to provide supporting information for the evaluation of Factor 5, Small Business Utilization and Participation. It requires offerors to document their historical small business utilization and achievements for each project submitted under Factor 1, Corporate Experience.

• Offerors must complete the "PROJECT DETAILS" section for each project submitted under Factor 1, Corporate Experience.
• This includes contract/task order number, project title, offeror's business size, how the contract was performed (prime, subcontractor, JV), and whether a subcontracting plan was required.
• Offerors must complete the "ACTUAL" column for all projects, entering dollar values and percentages of subcontracted amounts for various small business categories (Small Business, SDB, WOSB, HUBZone, VOSB, SDVOSB) and large business concerns.
• The "GOAL" column is to be completed if applicable, detailing the established goals for subcontracting.
• Specific instructions are provided for handling task orders, standalone contracts, and situations where goals were not established or were unmet.
• Explanations are required for any unmet goals or for projects with no small business subcontracting achievement.
• Definitions for "Total Project Dollar Value," "Total Self-Performed Value," and "Total Subcontract Value" are provided.

This form is critical for bidders to demonstrate their commitment and past performance in utilizing small businesses. Accurate and complete submission of historical small business utilization data is required for the evaluation of Factor 5. Offerors must adhere strictly to the format and instructions provided, as information in a different format or on a self-created form will not be evaluated. Failure to provide sufficient detail or explanations for unmet goals may impact the evaluation of this factor.

Form / Attachment / Pricing Sheet

This document, "Attachment F - Small Business Participation Commitment Document (SBPCD)", is a mandatory form for all offerors (both large and small businesses) responding to the solicitation. It is used to provide supporting information for the evaluation of Factor 5, Small Business Utilization and Participation. This is the sole form that will be evaluated for determining an offeror's small business participation commitment. Information provided in any other format or on a different form will not be evaluated, nor will attachments or addendums to this form.

• Offeror Information: Includes prime contractor name, address, and preparation date.
• Prime Contractor Size: Offerors must indicate if they are a Large Business (LB) or Small Business (SB). If an SB, they must check all applicable socioeconomic categories (HUBZone, WOSB, EDWOSB, SDB, VOSB, SDVOSB) or select "None" if none apply.
• Subcontracting Breakdown: Requires the Total Contract Value (TCV) and the value of work to be self-performed by the prime offeror.
• Small Business Participation: Requires the total dollar value and percentage of the Total Contract Value (TCV) committed to Small Businesses (SBs), including all SB socioeconomic categories and work self-performed as an SB. A minimum subcontracting requirement of 20% is stated, and a detailed explanation is required if this minimum is not met.
• Specific SB Categories: Fields are provided to list dollar value and % of TCV for SDB, WOSB, HUBZone, VOSB, and SDVOSB.
• Detailed Explanation: Space is provided for offerors not proposing a minimum of 20% for small business participation to provide a detailed explanation.
• Subcontractor Commitments Table: A table to identify specific Small Businesses (SBs) with whom firm commitments are in place. This table requires Company Name, Small Business Category(ies), Products/Services, and Nature of Commitment. Only subcontractors with established firm commitments should be listed.
• Explanation/Rationale: If no subcontractors are identified in the table, a detailed explanation is required regarding why subcontractors are not identified with firm commitments and how the firm will achieve proposed small business participation.
• No Subcontracting Intent: If an offeror does not intend to subcontract, a detailed explanation is required as to why subcontracting would not result in efficient contract performance, unless the SB intends to 100% self-perform.

This document is critical for bidders to accurately document and commit to their small business participation strategy. Failure to complete this form correctly or meet the minimum participation requirements (if applicable) may impact the evaluation of proposals. Bidders must ensure they understand the requirements for documenting commitments and providing necessary explanations.

Form / Attachment / Pricing Sheet

This document is the Bid Price Schedule for the USCG OCR Homeport Initiative OPC Pier project at Newport Naval Station, Newport, RI. It requires bidders to provide unit prices and total prices for various line items related to the construction and demolition work.

• Base Price (Line Item 0001): Covers the demolition of the existing OPC Pier, construction of landside areas, new Bulkhead S45S, and the new OPC Pier 1. This is a lump sum item.
• Detailed Line Items (0001A - 0001R): These cover specific tasks such as construction of the new OPC Pier, demolition and disposal of debris, furnishing and installing various types of piles (steel pipe, HP 14x102", HP 10x42", polymeric fender), steel sheet pile sheeting, eel grass mitigation, demolition of existing Pier 1 and associated landside areas, soil removal and disposal (non-hazardous and hazardous), asbestos abatement (glazing compound, roofing), PCB-containing material removal (caulking, light ballasts, CMU/concrete/asphalt, transformers), mercury-containing thermostat removal, lead anchor/bollard removal, and dredging/disposal.
• Option Items (0002, 0003): Option Item No. 1 is for a Compressed Air System, and Option Item No. 2 is for cast-in-place concrete pavement instead of asphalt.
• General Bid Notes: Clarify that award will be based on the total proposed price including options. Quantities marked with an asterisk (*) are estimated. Variations in estimated quantities for unit-priced items may lead to equitable adjustments. Payment for piles is based on actual installed length. Failure to enter a price for any line item will result in rejection. The unit price will govern if there is a discrepancy with the extended total.

This document is critical for bidders to understand the specific pricing structure and the detailed breakdown of costs required for the project. Bidders must carefully review each line item, including base and option items, and provide accurate pricing. The General Bid Notes provide essential guidance on how pricing will be evaluated and potential adjustments, directly impacting proposal strategy and final contract value.

Form / Attachment / Pricing Sheet

This document, SECNAV FORM 5512/1, is the Local Population ID Card/Base Access Pass Registration form. It is used by individuals requesting access to Department of the Navy (DON) or U.S. Marine Corps installations/facilities. The form collects personal information for identity proofing and to adjudicate access.

• Personal Information: Name, race, gender, date and place of birth, citizenship status, and contact information.
• Identity Documents: Requires presentation of at least two forms of identification (e.g., U.S. Passport, Driver's License, Social Security Card) to verify identity and employment authorization.
• Prior Convictions & Compliance: Inquires about felony convictions and acknowledges compliance with the REAL ID Act.
• Authorization & Release: Applicant authorizes the DOD/DON to obtain necessary information for vetting and fitness determination.
• Base Registrar Section: For official use, documenting identity verification, NCIC checks, and pass issuance/expiration.

This form is directly relevant to any bidder or individual requiring physical access to a DON or U.S. Marine Corps installation as part of the opportunity. Bidders will need to complete this form accurately to obtain the necessary base access pass for participation in activities related to the opportunity, such as site visits, meetings, or performance of contracted work on-base. Failure to provide accurate information may result in denial of access.

Form / Attachment / Pricing Sheet

This document is a map indicating the location for a site visit. It provides visual guidance for attendees to navigate to the designated meeting point and parking areas.

• "Meet Here": Indicates the primary meeting location.
• "Gate 17": Identifies a specific entry gate.
• "Park here": Suggests areas for parking.
• Labels for key facilities such as USCG MAT Newport, Navy Child & Youth Program, US Naval Undersea Warfare Center, and Naval Station Fire Dept/ Police Dept.
• Road names (Burma Rd, Access Rd, Admiralty Dr, etc.) for navigation.

This map is crucial for bidders attending a site visit. It clarifies the exact location to meet, where to park, and how to access the facility, ensuring efficient and timely arrival for the site visit.

Form / Attachment / Pricing Sheet

This document is a General Decision Number (GDN) for wage rates in Rhode Island, applicable to building, heavy (heavy and marine), and highway construction projects. It serves as a reference for prevailing wages that must be paid on federal or federally funded construction projects in the state.

• General Decision Number: RI20260001, effective 01/30/2026.
• Superseded GDN: RI20250001.
• State and Counties: Rhode Island Statewide.
• Construction Types: Building, Heavy (Heavy and Marine), and Highway.
• Applicability: Excludes residential construction of single-family homes and apartments up to and including 4 stories.
• Wage Rates: Lists specific wage rates and fringe benefits for various trades and job classifications (e.g., Asbestos Worker/Insulator, Boiler Maker, Bricklayer, Carpenter, Electrician, Operating Engineer, Laborer, Painter, Plasterer, Plumber, Roofer, Sheet Metal Worker, Truck Driver, Welder).
• Modifications: Includes modification numbers and publication dates, indicating updates to the wage rates.
• Footnotes: Provides specific conditions, additional pay, or holiday pay rules for certain classifications.

Bidders must use these prevailing wage rates to accurately estimate labor costs for their proposals. Failure to comply with these wage requirements can lead to bid disqualification or contract non-compliance. This document is crucial for understanding the labor cost component of any construction opportunity in Rhode Island covered by this wage determination.

Specifications / Other

This document compilation outlines specifications and environmental data relevant to the USCG OPC Homeport Initiative Pier project at Naval Station Newport, RI. It includes detailed technical specifications for construction materials and systems such as concrete, metals, fiberglass reinforced plastic (FRP) lumber, electrical components, HVAC systems, lighting, piles, utilities, paving, landscaping, mooring fittings, and dredging. Environmental data includes laboratory reports and data validation worksheets for soil and groundwater sampling at Site 19 (Former Derecktor Shipyard), Operable Units 5 and 12, detailing contaminants like asbestos, RCRA metals, PCBs, mercury, and petroleum hydrocarbons. A Soil Management Plan (SMP) Version 2 Final is also included, establishing new arsenic standards and outlining procedures for managing disturbed or excavated soil, excess soils, offsite disposal, exposed soils, clean fill, decontamination, worker health and safety, and engineering controls.

Bidders must review these specifications to understand the precise requirements for materials, fabrication, installation, testing, and quality control. The environmental data and Soil Management Plan are critical for assessing site conditions, potential hazards, remediation needs, and compliance requirements for any contracts involving construction, demolition, or excavation at Naval Station Newport, particularly Site 19. The SMP details strict procedures for soil handling, disposal, and capping, worker safety, and engineering controls that must be adhered to. Understanding these technical and environmental aspects is essential for accurate cost estimation, safety planning, and successful contract execution.

Forms / Attachments / Pricing Sheets

This document contains the "Title Sheet" (Sheet G-001) and detailed construction drawings for the USCG OCR Homeport Initiative OPC Pier project at Naval Station Newport, Rhode Island. It serves as the primary organizational document for the entire drawing set and outlines site preparation, utility, and construction details.

• Project Identification: USCG OCR Homeport Initiative OPC Pier, Naval Station Newport, Rhode Island. Project Number: 1826479, NAVFAC Drawing Number: 12936570.
• Drawing Set Organization: Sheet G-001 is the Title Sheet, part of a 247-sheet set.
• Site Demolition Plan (CD101): Details demolition of existing structures and pavement.
• Utility Plans (CD102, C-101 to C-103, C-201, C-202): Illustrate existing and proposed utilities (water, sewer, storm drainage, electrical, compressed air) and their profiles.
• Site Layout & Details (C-101, C-501 to C-507): Includes overall site plan, erosion control measures, and specific construction details for pavement, curbs, manholes, pump stations, and bio-retention areas.
• Project Information: General notes and abbreviations (C-001, C-002) provide project guidelines.
• Approvals: Lists approving authorities and dates.

This document is crucial for bidders to understand the project scope, location, and specific construction requirements. It provides essential identifying information for the drawing set and details the necessary site preparation, demolition, utility work, and construction elements required for accurate bidding and project execution. Bidders must use these drawings to confirm they have the complete set and to plan their approach to the work.

Form / Attachment / Pricing Sheet

This document is an index of drawings for the "USCG OCR HOMEPORT INITIATIVE OPC PIER" project located at Naval Station Newport, Newport, Rhode Island. It serves as a table of contents for all associated technical drawings.

• General Sheet Index: Lists drawings related to general project information, site controls, arrangement plans, and access routes.
• Geotechnical Sheet Index: Details drawings concerning soil boring logs and estimated top of weathered rock contours.
• Dredge Sheet Index: Outlines plans and sections related to dredging activities.
• Hazardous Materials Sheet Index: Identifies drawings pertaining to hazardous materials.
• Civil Sheet Index: Covers site plans, utility plans, and erosion control details.
• Survey Sheet Index: Lists drawings related to existing site conditions and surveys.
• Structural Sheet Index: Encompasses a comprehensive list of structural drawings, including demolition plans, bulkhead plans, pier details, framing plans, pile plans, and various sections and elevations.
• Mechanical Sheet Index: Details drawings for mechanical systems, including plans, sections, and schematics.
• Electrical Sheet Index: Lists drawings for electrical systems, including site plans, deck plans, grounding, lightning protection, substations, and panel schedules.
• Electrical Substation 1 Sheet Index: Specifically details drawings for Electrical Substation 1.

This index is crucial for bidders to understand the scope and organization of the project's technical documentation. It allows potential bidders to quickly locate specific drawings relevant to their area of expertise or interest, such as structural, mechanical, or electrical components, and to assess the overall complexity and detail of the project's design.

Form / Attachment / Pricing Sheet

This document is an index of drawings for the USCG OCR Homeport Initiative OPC Pier project. It lists all the drawing numbers, their titles, and their corresponding NAVFAC drawing numbers. This index is crucial for navigating the project's technical documentation.

• General Sheet Index: Lists general drawings such as title sheets, index of drawings, abbreviations, site plans, and arrangement plans.
• Geotechnical Sheet Index: Details drawings related to soil boring logs and subsurface profiles.
• Dredge Sheet Index: Outlines plans related to dredging operations.
• Hazardous Materials Sheet Index: Identifies drawings concerning hazardous materials.
• Civil Sheet Index: Includes site plans, utility plans, and site details.
• Structural Sheet Index: Covers demolition plans, bulkhead plans, framing plans, pile plans, and various structural sections and details.
• Survey Sheet Index: Contains drawings related to existing site conditions and surveys.
• Mechanical Sheet Index: Lists drawings for mechanical systems, including plans, sections, and schedules.
• Electrical Sheet Index: Details electrical plans, substation details, grounding plans, and lighting plans.
• Electrical Substation 1 Sheet Index: Specific index for electrical substation drawings.

This index is essential for bidders to understand the scope and complexity of the project by providing a comprehensive overview of all technical drawings. It allows for efficient retrieval of specific information related to structural, civil, mechanical, and electrical components, as well as geotechnical data and demolition plans, which are critical for accurate bidding and proposal development.

Forms / Attachments / Pricing Sheets

This document is an index of drawings for the USCG OCR Homeport Initiative OPC Pier project at Naval Station Newport, Rhode Island. It serves as a table of contents for all technical drawings associated with the project.

• General Sheet Index: Lists all general drawings, including title sheets, index of drawings, abbreviations, site plans, and arrangement plans.
• Geotechnical Sheet Index: Details drawings related to soil borings and geotechnical surveys.
• Structural Sheet Index: Encompasses drawings for structural demolition, plans, elevations, sections, details, and schedules.
• Dredge Sheet Index: Contains plans and sections related to dredging operations.
• Hazardous Materials Sheet Index: Lists drawings pertaining to hazardous materials.
• Civil Sheet Index: Includes drawings for civil site work, demolition, utilities, and site details.
• Survey Sheet Index: Details drawings related to existing conditions and surveys.
• Mechanical Sheet Index: Covers mechanical plans, sections, schedules, and details for various systems.
• Electrical Sheet Index: Includes electrical plans, site plans, substation details, and schedules.
• Electrical Substation 1 Sheet Index: Specific drawings for electrical substation 1.

This index is crucial for bidders to understand the scope and organization of the project's technical documentation. It allows vendors to quickly locate specific drawings relevant to their bid, such as structural, mechanical, or electrical plans, enabling a more accurate assessment of project requirements and costs.

Forms / Attachments / Pricing Sheets

This document is an index of all drawings associated with the USCG OCR Homeport Initiative OPC Pier project. It serves as a table of contents for the project's technical documentation.

• General Sheet Index: Lists all general drawings, including title sheets, index sheets, abbreviations, site plans, and arrangement plans.
• Geotechnical Sheet Index: Details drawings related to soil borings and geotechnical analysis.
• Dredge Sheet Index: Outlines drawings pertaining to dredging plans and sections.
• Hazardous Materials Sheet Index: Identifies drawings related to hazardous materials.
• Civil Sheet Index: Covers civil engineering drawings such as site plans, utility plans, and site details.
• Structural Sheet Index: Includes drawings for structural elements, demolition plans, and details.
• Electrical Sheet Index: Lists all electrical drawings, including legends, site plans, deck plans, substation details, grounding plans, lightning protection, and panel schedules.
• Mechanical Sheet Index: Details mechanical system drawings, including plans, sections, and schematics.
• Survey Sheet Index: Contains drawings related to existing conditions and surveys.

This index is crucial for bidders to understand the scope and organization of the project's technical documentation. It allows for efficient navigation and retrieval of specific drawings required for proposal preparation, cost estimation, and understanding project requirements.

Solicitation / RFP / RFQ

This is a pre-solicitation synopsis for a Design-Bid-Build construction project to demolish an existing U.S. Navy pier and construct a new pier, bulkhead, laydown area, parking, and associated utilities (stormwater management, fire/potable water, electrical, telecommunications, compressed air) for Offshore Patrol Cutters (OPCs) at Naval Station Newport, Newport, RI.

• Demolition of an existing 1,570' x 100' pier.

• Construction of a new 1,000' x 80' pier.

• Construction of a new 360' bulkhead.

• Development of a laydown area and parking.

• Installation of stormwater management, fire/potable water, electrical, telecommunications, and compressed air utilities.

• Project completion is required within 1000 calendar days after award.

• This procurement is for "Unrestricted" full and open competition.

• The contract type will utilize the best value continuum process (Tradeoff).

• The estimated magnitude of construction is between $100,000,000 to $250,000,000.

• Anticipated award date is September 2026.

• The solicitation will be advertised as "Unrestricted" for full and open competition.

• Source selection will require both non-price (technical and past performance) and price proposals.

• Evaluation factors will be included in the solicitation.

• Market research indicated that there is not a reasonable expectation that an adequate number of Small Business firms would respond or be qualified for this solicitation.

• Therefore, the contract will be solicited as "Unrestricted" for full and open competition.

• Large business concerns are required to submit a subcontracting plan prior to award.

• The North American Industry Classification System (NAICS) code is 237990 – Other Heavy and Civil Engineering Construction, with a Small Business Size Standard of $45,000,000.

• The Request for Proposal (RFP) is expected to be issued on or about March 5, 2026, under solicitation number N40085-26-R-0001.

• All documents will be available in Adobe PDF format on the PIEE and Sam.gov websites.

• Prospective offerors must be registered in the System for Award Management (SAM).

• Questions should be directed to Kristy Gerrek at kristy.l.gerrek.civ@us.navy.mil.

Form / Attachment / Pricing Sheet

This form is a "Contractor Information Form" intended to collect general information from potential contractors. Bidders are instructed to limit their response to one page and use the provided space for clarifications.

• Contractor Information: Fields for UEI, CAGE Code, Firm Name, and Address.
• Point of Contact (POC) Information: Name, Phone Number, and Email of the firm's POC.
• Type of Business: Checkboxes for various small business designations (e.g., Large Business, SBA certified 8(a) firm, HUBZone, SDVOSB, VOSB, WOSB, EDWOSB).
• Bonding Capacity: Information on Surety Name, Maximum bonding capacity per project, and Aggregate maximum bonding capacity.
• Additional Information: A space for any further clarifications.

This form requires bidders to provide essential identifying and business classification details. Completing this form accurately is likely a prerequisite for participation in the opportunity or for proposal evaluation, particularly concerning small business status and bonding capabilities.

Solicitation / RFP / RFQ

This is a Sources Sought Notice, not a Request for Proposal, Quote, or Invitation for Bid. The Naval Facilities Engineering Systems Command, Mid-Atlantic is conducting market research to determine the availability of eligible small businesses capable of performing construction services for the USCG Offshore Patrol Cutters (OPC) Homeport Pier at Naval Station Newport, Newport RI. The intent is to assess if a set-aside procurement is in the Government's best interest.

This Design-Bid-Build project involves demolishing an existing condemned US Navy pier and constructing a new pier (1,000' long x 80' wide) to accommodate four Offshore Patrol Cutters (OPCs). The project also includes a new bulkhead, laydown area, stormwater management, and utilities (fire/potable water, electrical, telecommunications, compressed air).

• Magnitude of construction: Between $100,000,000 and $250,000,000.

• Anticipated award: September 2026.

• NAICS Code: 237990 (Other Heavy and Civil Engineering Construction) with a small business size standard of $45,000,000.

• Interested sources must submit a Capabilities Statement using the attached "Sources Sought Contractor Information Form" and "Project Information Form".

• Responses are due by 04 February 2026, 2:00 P.M. local time.

• Submissions must be electronic to Kristy.l.gerrek.civ@us.navy.mil, limited to a 4MB attachment.

• Late or incomplete responses will not be considered.

• Questions or comments can be emailed to Kristy.l.gerrek.civ@us.navy.mil.

• Small businesses (SDVOSB, HUB-Zone, 8(a), WOSB) are encouraged to respond.

• Large business submittals will not be considered.

• If set aside for small businesses, FAR clause 52.219-14 (Limitations on Subcontracting) will apply, requiring at least 15% of the contract cost (excluding materials) to be performed by the prime contractor's employees.

• If adequate small business interest is not received, the solicitation may be issued as unrestricted.

• For 8(a) Mentor-Protégé joint ventures, SBA approval of the agreement is required.

• This is a market research tool; it is not a request for proposal.

• The Government will not pay for information received.

• Information submitted will be held confidentially and used only for market research purposes.

• The Capabilities Statement is not expected to be a proposal, but a statement of the company's ability and experience.

• Experience requirements include specific size ($75M+), scope (reinforced concrete wharfs/pier structures), and complexity (demonstrating five of six listed elements like steel pile support, demolition, drilled piles, industrial utilities, civil work).

• Prime contractor experience is required; subcontractor experience is generally not considered, except for small businesses utilizing first-tier subcontractors under specific conditions.

Form / Attachment / Pricing Sheet

This document is a "Project Information Form" intended for bidders to submit supporting information demonstrating relevant project experience. It is designed to be used for each project submitted, with a limit of up to five projects per response, and a maximum of two pages per project.

• Contractor Information: Name, Contract Number, Delivery/Task Order Number, Project Number, Title, Location.
• Project Details: Award Date, Final Contract Price, Completion Date, Percentage Complete.
• Work Type: Categorization into New Construction, Repair, or Renovation.
• Customer Information: Name, Point of Contact (Name, Title, Phone, Email).
• Contracting Role: Prime contractor or subcontractor status, including prime contractor name if applicable.
• Contract Type: Options include Design-Build, Design-Bid-Build, or Other, with specific fields for Design-Build details (in-house design, lead firm, years working together, address).
• Project Description: Detailed description of the overall project.
• Self-Performed Work: Percentage of work self-performed and a detailed description of that work.

This form is crucial for bidders to showcase their past performance and relevant experience. Completing it accurately and thoroughly will help the government assess a bidder's capability to perform on the subject opportunity. Bidders must provide specific details about up to five projects, including contract values, timelines, types of work, and their role (prime or sub) to demonstrate their qualifications.

Other / Unclassified

This document is a collection of sign-in sheets from an Industry Day event for the USCG OCR Homeport Initiative OPC Pier at NAVSTA Newport, RI. The event took place at the Crowne Plaza Hotel in Warwick, RI, on December 4, 2025.

This document provides a list of attendees from various organizations who participated in the Industry Day. It includes their names, organizations/roles, telephone numbers, and email addresses. This information can be valuable for potential bidders to identify key contacts, understand industry presence, and potentially network with other interested parties or government representatives who attended the event.

Solicitation / RFP / RFQ

This document presents slides from an Industry Day for the USCG OPC Pier project at Naval Station Newport, Rhode Island. The purpose is to notify industry of the upcoming solicitation, inform them of the project's scope, timeline, and potential challenges, and solicit private sector input. This is an informational meeting and not a Request For Proposal (RFP).

• Demolish existing USN Pier 1 (1586-ft long).

• Construct a new pier (80-ft wide by 1000-ft long) to accommodate four Offshore Patrol Cutters (OPCs).

• Support utilities including electrical, telecommunications, potable and fire protection water, and sewer.

• Install mooring devices, deck fittings, and fenders.

• Construct a new bulkhead at Section S45 South.

• Dredging required beneath the existing Pier 1 to achieve depths between 32-40 ft MLLW, with a required minimum berthing depth of 23 ft MLLW and a required channel depth of 27 ft MLLW.

• Structural components include 36" concrete-filled steel pipe piles, reinforced concrete beam and pile cap framing, and precast concrete deck planks.

• Fire lane down the middle of the pier (20-ft total width, 15-ft unobstructed).

• Fire water supply system sized to deliver 2,000 GPM at 20 PSI residual pressure.

• Construction Contract Award is anticipated in September 2026.

• Construction is estimated to be complete by October 2029 (1000 calendar days).

• RFP Issue Date: February 2026

• Site Visit: March 2026

• Proposals Due: April 2026

• Acquisition Strategy: Full and Open Solicitation, Best Value Source Selection (BVSS) with Tradeoffs (Experience, Safety, Past Performance, Small Business Utilization, Management Approach and Schedule).

• Project Labor Agreement to be determined.

• All information presented is a DRAFT and subject to change.

• Questions can be submitted in writing to philip.j.cole.civ@us.navy.mil.

Form / Attachment / Pricing Sheet

This document is an industry day registration form for the OPC HOMEPORT BUILD NEW PIER opportunity at Naval Station Newport, Rhode Island. It is used to collect contact information from interested companies wishing to attend the industry day event.

• Company Name
• Contact Person's Name
• Contact Person's Email
• Contact Person's Phone Number
• Company Address

Companies interested in attending the industry day for this opportunity must complete and submit this form. It is essential for gathering information about potential attendees and facilitating communication regarding the event.

Other / Unclassified

This document is an Industry Day flyer for the OPC Homeport Pier project at Naval Station Newport, Rhode Island. It announces an event hosted by Naval Facilities Engineering Systems Command, Mid-Atlantic (NAVFAC MIDLANT) to provide industry with an overview of the project, answer questions, and collect feedback.

This flyer is relevant to potential bidders as it outlines:

• Project Scope: Demolition of an existing US Navy pier and construction of a new pier for four Offshore Patrol Cutters (OPCs), including a new bulkhead, laydown area, parking, and utilities.
• Project Cost Range: Estimated between $100M - $250M.
• Industry Day Details:
  • Date: Thursday, December 4, 2025
  • Time: Check-in begins at 8:30 AM
  • Location: Crowne Plaza Providence-Warwick (Airport), 801 Greenwich Ave, Warwick, RI 02886
• Anticipated Discussion Topics: The Coast Guard Mission, Project Overview, and Project Schedule.
• Registration: Encouraged but not required. Interested parties (prime and subcontractors) should provide company name, address, POC, email, and phone number. Registration is due by Monday, December 1, 2025, via email to Kristy Gerrek at kristy.l.gerrek.civ@us.navy.mil. Attendees should identify if they are a prime contractor.